10-Q 1 form10-q.htm FORM 10-Q form10-q.htm


UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549

FORM 10-Q

(Mark one)
x
QUARTERLY REPORT PURSUANT TO SECTION 13 or 15(d) OF THE SECURITIES
EXCHANGE ACT OF 1934
 
For the quarterly period ended April 2, 2010
   
OR
 
o
TRANSITION REPORT PURSUANT TO SECTION 13 or 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

For the Transition Period from ____________ to _____________

Commission file number 1-7567
Logo
URS CORPORATION
(Exact name of registrant as specified in its charter)

Delaware
94-1381538
(State or other jurisdiction of incorporation or organization)
(I.R.S. Employer Identification No.)
   
600 Montgomery Street, 26th Floor
 
San Francisco, California
94111-2728
(Address of principal executive offices)
(Zip Code)

(415) 774-2700
(Registrant’s telephone number, including area code)
 
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.  Yes x No o
 
Indicate by check mark whether the registrant has submitted electronically and posted on its corporate web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files).  Yes o No o
 
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company.  See the definitions of “large accelerated filer,” “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act.
 
Large accelerated filer x Accelerated filer o Non-accelerated filer o Smaller reporting company o
 
Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).  Yes o No x
 
Indicate the number of shares outstanding of each of the issuer’s classes of common stock, as of the latest practicable date.
 
16BClass
 
Outstanding at May 3, 2010
     
Common Stock, $.01 par value
 
82,814,926




 
 
 
 

This Quarterly Report on Form 10-Q contains forward-looking statements within the meaning of the Private Securities Litigation Reform Act of 1995.  These forward-looking statements may be identified by words such as “anticipate,” “believe,” “estimate,” “expect,” “potential,” “intend,” “may,” “plan,” “predict,” “project,” “will,” and similar terms used in reference to our future revenues, services and other business trends; potential new project awards and other opportunities; future accounting and actuarial estimates; future backlog conversion; future income taxes; future stock-based compensation expenses; future bonus, pension and post-retirement expenses; future compliance with regulations; future legal proceedings and accruals; future bonding and insurance coverage; future interest and debt payments; future capital expenditures, contractual obligations and commitments; future capital resources; future federal government approval of our billing practices; future effectiveness of our disclosure and internal controls over financial reporting and future economic and industry conditions.  We believe that our expectations are reasonable and are based on reasonable assumptions, however, we caution against relying on any of our forward-looking statements as such forward-looking statements by their nature involve risks and uncertainties.  A variety of factors, including but not limited to the following, could cause our business and financial results, as well as the timing of events, to differ materially from those expressed or implied in our forward-looking statements:  economic weakness and declines in client spending; changes in our book of business; our compliance with government contract procurement regulations; employee, agent or partner misconduct; our ability to procure government contracts; liabilities for pending and future litigation; environmental liabilities; availability of bonding and insurance; our reliance on government appropriations; unilateral termination provisions in government contracts; our ability to make accurate estimates and assumptions; our accounting policies; workforce utilization; our and our partners’ ability to bid on, win, perform and renew contracts and projects; liquidated damages; our dependence on partners, subcontractors and suppliers; customer payment defaults; our ability to recover on claims; impact of target and fixed-priced contracts on earnings; the inherent dangers at our project sites; impairment of our goodwill; the impact of changes in laws and regulations; nuclear indemnifications and insurance; a decline in defense spending; industry competition; our ability to attract and retain key individuals; retirement plan obligations; integration of acquisitions; our leveraged position and the ability to service our debt; restrictive covenants in our credit agreement; risks associated with international operations; business activities in high security risk countries; third-party software risks; natural and man-made disaster risks; our relationships with labor unions; our ability to protect our intellectual property rights; anti-takeover risks and other factors discussed more fully in Management’s Discussion and Analysis of Financial Condition and Results of Operations beginning on page 33, Risk Factors beginning on page 55, as well as in other reports subsequently filed from time to time with the United States Securities and Exchange Commission.  We assume no obligation to revise or update any forward-looking statements.
 
FINANCIAL INFORMATION:
 
     
Item 1.
Financial Statements
 
   
  2
   
 
   
 
   
  5
   
 
 
Item 2.
33
Item 3.
Item 4.
     
PART II.
OTHER INFORMATION:
 
     
Item 1.
Item 1A.
Item 2.
Item 3.
Item 4.
Item 5.
Item 6.


PART I
FINANCIAL INFORMATION
 
ITEM 1.  FINANCIAL STATEMENTS
 
2BURS CORPORATION AND SUBSIDIARIES
3BCONDENSED CONSOLIDATED BALANCE SHEETS - UNAUDITED
4B(In thousands, except per share data)
 
   
April 2, 2010
   
January 1, 2010
 
ASSETS
           
Current assets:
           
Cash and cash equivalents
  $ 638,451     $ 720,621  
Short-term investments
    633       30,682  
Accounts receivable, including retentions of $59,621 and $41,771, respectively
    1,010,154       924,271  
Costs and accrued earnings in excess of billings on contracts
    1,205,700       1,024,215  
Less receivable allowances
    (46,500 )     (47,651 )
Net accounts receivable
    2,169,354       1,900,835  
Deferred tax assets
    73,462       98,198  
Other current assets
    120,712       130,484  
Total current assets
    3,002,612       2,880,820  
Investments in and advances to unconsolidated joint ventures
    97,450       93,874  
Property and equipment at cost, net
    247,932       258,950  
Intangible assets, net
    415,739       425,860  
Goodwill
    3,171,084       3,170,031  
Other assets
    80,103       74,881  
Total assets
  $ 7,014,920     $ 6,904,416  
LIABILITIES AND EQUITY
               
Current liabilities:
               
Current portion of long-term debt
  $ 16,337     $ 115,261  
Accounts payable and subcontractors payable, including retentions of $55,911 and $51,475, respectively
    615,960       586,783  
Accrued salaries and employee benefits
    466,463       435,456  
Billings in excess of costs and accrued earnings on contracts
    212,621       235,268  
Other current liabilities
    128,231       156,746  
Total current liabilities
    1,439,612       1,529,514  
Long-term debt
    788,032       689,725  
Deferred tax liabilities
    305,963       324,711  
Self-insurance reserves
    112,605       101,338  
Pension and post-retirement benefit obligations
    166,532       172,248  
Other long-term liabilities
    140,182       136,415  
Total liabilities
    2,952,926       2,953,951  
Commitments and contingencies (Note 14)
               
URS stockholders’ equity:
               
Preferred stock, authorized 3,000 shares; no shares outstanding
           
Common stock, par value $.01; authorized 200,000 shares; 85,851 and 86,071 shares issued, respectively; and 82,799 and 84,019 shares outstanding, respectively
    858       860  
Treasury stock, 3,052 and 2,052 shares at cost, respectively
    (132,222 )     (83,810 )
Additional paid-in capital
    2,884,681       2,884,941  
Accumulated other comprehensive loss
    (45,515 )     (49,239 )
Retained earnings
    1,248,682       1,153,062  
Total URS stockholders’ equity
    3,956,484       3,905,814  
Noncontrolling interests
    105,510       44,651  
Total stockholders’ equity
    4,061,994       3,950,465  
Total liabilities and stockholders’ equity 
  $ 7,014,920     $ 6,904,416  
 
See Notes to Condensed Consolidated Financial Statements



URS CORPORATION AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF OPERATIONS - UNAUDITED
(In thousands, except per share data)

   
Three Months Ended
 
   
April 2,
2010
   
April 3,
2009
 
Revenues
  $ 2,207,476     $ 2,520,638  
Cost of revenues
    (2,086,747 )     (2,379,423 )
General and administrative expenses
    (20,164 )     (18,085 )
Equity in income of unconsolidated joint ventures
    24,657       40,013  
Operating income
    125,222       163,143  
Interest expense
    (9,372 )     (14,723 )
Other expenses
          (7,584 )
Income before income taxes
    115,850       140,836  
Income tax expense
    (2,182 )     (57,635 )
Net income
    113,668       83,201  
Noncontrolling interests in income of consolidated subsidiaries, net of tax
    (18,048 )     (7,729 )
Net income attributable to URS
  $ 95,620     $ 75,472  
                 
                 
Earnings per share (Note 3):
               
Basic
  $ 1.17     $ .93  
Diluted
  $ 1.17     $ .92  
Weighted-average shares outstanding (Note 3):
               
Basic
    81,384       81,492  
Diluted
    81,912       82,018  
 
See Notes to Condensed Consolidated Financial Statements


URS CORPORATION AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF COMPREHENSIVE INCOME - UNAUDITED
(In thousands, except per share data)

   
Three Months Ended
 
   
April 2,
2010
   
April 3,
2009
 
Comprehensive income (loss):
           
Net income
  $ 113,668     $ 83,201  
Pension and post-retirement related adjustments, net of tax
    1,693       43  
Foreign currency translation adjustments, net of tax
    1,145       (4,677 )
Unrealized loss on foreign currency forward contract, net of tax
          (7,617 )
Unrealized gain on interest rate swaps, net of tax
    886       1,227  
Comprehensive income
    117,392       72,177  
Noncontrolling interests in comprehensive income of consolidated subsidiaries, net of tax
    (18,048 )     (7,729 )
Comprehensive income attributable to URS
  $ 99,344     $ 64,448  
 
See Notes to Condensed Consolidated Financial Statements


URS CORPORATION AND SUBSIDIARIES
7B CONDENSED CONSOLIDATED STATEMENTS OF CHANGES IN STOCKHOLDERS’ EQUITY – UNAUDITED
B(In thousands)

   
Common Stock
     Treasury Stock    
Additional
Paid-in
Capital
    Accumulated Other Comprehensive Income (Loss)     Retained Earnings     Total URS Stockholders’ Equity     Noncontrolling Interests    
Total
Equity
 
   
Shares
   
Amount
                             
Balances, January 2, 2009
    83,952     $ 850     $ (42,585 )   $ 2,838,290     $ (55,866 )   $ 883,942     $ 3,624,631     $ 31,125     $ 3,655,756  
Employee stock purchases and exercises of stock options, net
    (67 )     (1 )           (3,279 )                 (3,280 )           (3,280 )
Stock-based compensation
    (49 )     (1 )           8,571                   8,570             8,570  
Tax benefit from stock-based compensation
                      511                   511             511  
Foreign currency translation adjustments, net of tax
                            (4,677 )           (4,677 )           (4,677 )
Pension and post-retirement related adjustments, net of tax
                            43             43             43  
Interest rate swaps, net of tax
                            1,227             1,227             1,227  
Purchase of treasury stock
    (638 )           (23,972 )                       (23,972 )           (23,972 )
Unrealized loss on foreign currency forward contract, net of tax
                            (7,617 )           (7,617 )           (7,617 )
Distributions to noncontrolling interests
                                              (15,417 )     (15,417 )
Contributions and advances from noncontrolling interests
                                              800       800  
Other transactions with noncontrolling interests
                                              704       704  
Net income
                                  75,472       75,472       7,729       83,201  
Balances, April 3, 2009
    83,198     $ 848     $ (66,557 )   $ 2,844,093     $ (66,890 )   $ 959,414     $ 3,670,908     $ 24,941     $ 3,695,849  
                                                                         
Balances, January 1, 2010
    84,019     $ 860     $ (83,810 )   $ 2,884,941     $ (49,239 )   $ 1,153,062     $ 3,905,814     $ 44,651     $ 3,950,465  
Employee stock purchases and exercises of stock options, net
    (247 )     (2 )           (13,598 )                 (13,600 )           (13,600 )
Stock-based compensation
    27                   10,430                   10,430             10,430  
Excess tax benefits from stock-based compensation
                      2,908                   2,908             2,908  
Foreign currency translation adjustments, net of tax
                            1,145             1,145             1,145  
Pension and post-retirement related adjustments, net of tax
                            1,693             1,693             1,693  
Interest rate swaps, net of tax
                            886             886             886  
Purchase of treasury stock
    (1,000 )           (48,412 )                       (48,412 )           (48,412 )
Newly consolidated joint ventures
                                              40,975       40,975  
Distributions to noncontrolling interests
                                              (5,928 )     (5,928 )
Contributions and advances from noncontrolling interests
                                              7,327       7,327  
Other transactions with noncontrolling interests
                                              437       437  
Net income
                                  95,620       95,620       18,048       113,668  
Balances, April 2, 2010
    82,799     $ 858     $ (132,222 )   $ 2,884,681     $ (45,515 )   $ 1,248,682     $ 3,956,484     $ 105,510     $ 4,061,994  
 
See Notes to Condensed Consolidated Financial Statements


URS CORPORATION AND SUBSIDIARIES
5BCONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS - UNAUDITED
6B(In thousands)

   
Three Months Ended
 
   
April 2,
2010
   
April 3,
2009
 
Cash flows from operating activities:
           
Net income
  $ 113,668     $ 83,201  
Adjustments to reconcile net income to net cash from operating activities:
               
Depreciation
    19,841       22,670  
Amortization of intangible assets
    11,147       13,206  
Amortization of debt issuance costs
    3,088       1,963  
Unrealized loss on foreign currency forward contract
          6,225  
Normal profit
    20       (1,466 )
Provision for doubtful accounts
    664       1,550  
Deferred income taxes
    6,786       31,700  
Stock-based compensation
    10,430       8,583  
Excess tax benefits from stock-based compensation
    (2,908 )     (511 )
Equity in income of unconsolidated joint ventures, less dividends received
    (7,329 )     (17,116 )
Changes in operating assets, liabilities and other, net of effects of newly consolidated joint ventures:
               
Accounts receivable and costs and accrued earnings in excess of billings on contracts
    (147,101 )     46,824  
Other current assets
    7,251       32,888  
Advances to unconsolidated joint ventures
    (4,591 )     13,863  
Accounts payable, accrued salaries and employee benefits, and other current liabilities
    (52,968 )     (12,921 )
Billings in excess of costs and accrued earnings on contracts
    (30,442 )     (10,045 )
Other long-term liabilities
    8,232       1,333  
Other assets, net
    (1,759 )     (629 )
Total adjustments and changes
    (179,639 )     138,117  
Net cash from operating activities
    (65,971 )     221,318  
Cash flows from investing activities:
               
Cash related to newly consolidated joint ventures
    20,696        
Proceeds from disposal of property and equipment
    977       1,438  
Investments in unconsolidated joint ventures
    (2,518 )     (6,544 )
Changes in restricted cash
    (152 )     (512 )
Capital expenditures, less equipment purchased through capital leases and equipment notes
    (7,425 )     (9,252 )
Maturity of short-term investment
    30,049        
Net cash from investing activities
    41,627       (14,870 )
Cash flows from financing activities:
               
Long-term debt principal payments
    (2,643 )     (2,743 )
Net payments under lines of credit and short-term notes
    (349 )     (69 )
Net change in overdrafts
    (4,619 )     3,173  
Capital lease obligation payments
    (1,742 )     (1,635 )
Excess tax benefits from stock-based compensation
    2,908       511  
Proceeds from employee stock purchases and exercises of stock options
    1,108       822  
Net distributions to noncontrolling interests
    (4,077 )     (19,109 )
Purchase of treasury stock
    (48,412 )     (23,972 )
Net cash from financing activities
    (57,826 )     (43,022 )
Net increase (decrease) in cash and cash equivalents
    (82,170 )     163,426  
Cash and cash equivalents at beginning of period
    720,621       223,998  
Cash and cash equivalents at end of period
  $ 638,451     $ 387,424  
 
See Notes to Condensed Consolidated Financial Statements


 
URS CORPORATION AND SUBSIDIARIES
7BCONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS – UNAUDITED (continued)
8B(In thousands)

   
Three Months Ended
 
   
April 2,
2010
   
April 3,
2009
 
Supplemental information:
           
Interest paid
  $ 6,351     $ 13,247  
Taxes paid
  $ 2,817     $ 9,892  
Taxes refunded
  $     $ 30,000  
                 
Supplemental schedule of noncash investing and financing activities:
               
Equipment acquired with capital lease obligations and equipment note obligations
  $ 1,787     $ 1,941  
 
See Notes to Condensed Consolidated Financial Statements

7

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED



0B NOTE 1.  BUSINESS, BASIS OF PRESENTATION, AND ACCOUNTING POLICIES
 
1BOverview
 
The terms “we,” “us,” and “our” used in these financial statements refer to URS Corporation and its consolidated subsidiaries unless otherwise indicated.  We are a leading international provider of engineering, construction and technical services.  We offer a broad range of program management, planning, design, engineering, construction and construction management, operations and maintenance, and decommissioning and closure services to public agencies and private sector clients around the world.  We also are a major United States (“U.S.”) federal government contractor in the areas of systems engineering and technical assistance, and operations and maintenance.  Headquartered in San Francisco, we have more than 42,000 employees in a global network of offices and contract-specific job sites in more than 30 countries.  We operate through three reporting segments:  the Infrastructure & Environment business, the Federal Services business and the Energy & Construction business.
 
The accompanying unaudited condensed consolidated financial statements and related notes have been prepared in accordance with generally accepted accounting principles (“GAAP”) in the U.S. for interim financial information and with the instructions to Form 10-Q and Rule 10-01 of Regulation S-X.  Accordingly, they do not include all of the information and footnotes required by GAAP for complete financial statements.
 
You should read our unaudited condensed consolidated financial statements in conjunction with the audited consolidated financial statements and related notes contained in our Annual Report on Form 10-K for the year ended January 1, 2010.  The results of operations for the three months ended April 2, 2010 are not indicative of the operating results for the full year or for future years.
 
In our opinion, the accompanying unaudited condensed consolidated financial statements reflect all normal recurring adjustments that are necessary for a fair statement of our financial position, results of operations and cash flows for the interim periods presented.
 
The preparation of our unaudited condensed consolidated financial statements in conformity with GAAP requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities, and the disclosure of contingent assets and liabilities at the balance sheet dates as well as the reported amounts of revenues and costs during the reporting periods.  Actual results could differ from those estimates.  On an ongoing basis, we review our estimates based on information that is currently available.  Changes in facts and circumstances may cause us to revise our estimates.
 
Principles of Consolidation and Basis of Presentation
 
Our condensed consolidated financial statements include the financial position, results of operations and cash flows of URS Corporation and our majority-owned subsidiaries and joint ventures that are required to be consolidated.
 
Investments in unconsolidated joint ventures are accounted for using the equity method and are included as investments in and advances to unconsolidated joint ventures on our Condensed Consolidated Balance Sheets.  All significant intercompany transactions and accounts have been eliminated in consolidation.
 

8

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


Consolidation of Variable Interest Entities
 
We participate in joint ventures, which include partnerships and partially-owned limited liability companies to bid, negotiate and complete specific projects.  We are required to consolidate these joint ventures if we hold the majority voting interest or if we meet the criteria under the variable interest model as described below.
 
A variable interest entity (“VIE”) is an entity with one or more of the following characteristics (a) the total equity investment at risk is not sufficient to permit the entity to finance its activities without additional financial support; (b) as a group, the holders of the equity investment at risk lack the ability to make certain decisions, the obligation to absorb expected losses or the right to receive expected residual returns, or (c) an equity investor has voting rights that are disproportionate to its economic interest and substantially all of the entity’s activities are on behalf of the investor.
 
Our VIEs may be funded through contributions, loans and/or advances from the joint venture partners or by advances and/or letters of credit provided by our clients.  Our VIEs may be directly governed, managed, operated and administered by the joint venture partners.  Others have no employees and, although these entities own and hold the contracts with the clients, the services required by the contracts are typically performed by the joint venture partners or by other subcontractors.
 
If we are determined to be the primary beneficiary of the VIE, we are required to consolidate it.  We are considered to be the primary beneficiary if we have the power to direct the activities that most significantly impact the VIE’s economic performance and the obligation to absorb losses or the right to receive benefits of the VIE that could potentially be significant to the VIE.  In determining whether we are the primary beneficiary, our significant assumptions and judgments include the following:
 
·  
Identifying the significant activities and the parties that have the power to direct them;
 
·  
Reviewing the governing board composition and participation ratio;
 
·  
Determining the equity, profit and loss ratio;
 
·  
Determining the management-sharing ratio;
 
·  
Reviewing employment terms, including which joint venture partner provides the project manager; and
 
·  
Reviewing the funding and operating agreements.
 
Examples of significant activities include the following:
 
·  
Engineering services;
 
·  
Procurement services;
 
·  
Construction;
 
·  
Construction management; and
 
·  
Operations and maintenance services.
 
Based on the above, if we determine that the power to direct the significant activities is shared by two or more joint venture parties, then there is no primary beneficiary and no party consolidates the VIE.  In making the shared-power determination, we analyze the key contractual terms; governance; related party and de facto agency as they are defined in the accounting standard; and other arrangements to determine if the shared power exists.
 

9

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


As required by the accounting standard, we perform a quarterly reassessment of our status as primary beneficiary.  This evaluation may result in a newly consolidated joint venture or in deconsolidating a previously consolidated joint venture.  See Note 5, “Joint Ventures,” for further information on our VIEs.
 
Reclassifications
 
We made reclassifications to the prior years’ financial statements to conform them to the current period presentation.  These reclassifications have no effect on consolidated net income, stockholders’ equity or net cash flows.
 
Cash and Cash Equivalents
 
Cash and cash equivalents include all highly liquid investments with maturities of 90 days or less at the date of purchase and include interest-bearing bank deposits and money market funds.  Restricted cash was included in other current assets because it was not material.
 
At April 2, 2010 and January 1, 2010, cash and cash equivalents included $138.0 million and $112.4 million, respectively, of cash held by our consolidated joint ventures.
 
Short-Term Investments
 
At April 2, 2010, short-term investments consisted of all highly liquid investments, including interest-bearing time deposits, with maturities of more than 90 days, but less than a year, at the date of purchase.  The carrying values of our short-term investments approximate their fair values.
 
NOTE 2.  ADOPTED AND OTHER RECENTLY ISSUED ACCOUNTING STANDARDS
 
A new accounting standard on transfers of financial assets became effective for us at the beginning of our 2010 fiscal year.  This standard eliminates the concept of a qualifying special-purpose entity, limits the circumstances under which a financial asset is derecognized and requires additional disclosures concerning a transferor's continuing involvement with transferred financial assets.  The adoption of this standard did not have a material impact on our condensed consolidated financial statements.
 
A new accounting standard on consolidation of VIEs became effective for us at the beginning of our 2010 fiscal year.  This standard amends the accounting and disclosure requirements for the consolidation of a VIE.  It requires additional disclosures about the significant judgments and assumptions used in determining whether to consolidate a VIE, the restrictions on a consolidated VIE’s assets and on the settlement of a VIE’s liabilities, the risk associated with involvement in a VIE, and the financial impact to a company due to its involvement with a VIE.  As the standard requires ongoing quarterly evaluation of the application of the new requirements, changes in circumstances could result in the identification of additional VIEs to be consolidated or existing VIEs to be deconsolidated in any reporting period.  We adopted this standard prospectively and based on the carrying values of the entities at the date of adoption.  The adoption of this standard did not have a material impact on our condensed consolidated financial statements.  For additional disclosure, see Note 5, “Joint Ventures.”
 

10

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


An accounting standard update related to recurring and nonrecurring fair value measurements has been issued.  This update requires new disclosures on significant transfers of assets and liabilities between Level 1 and Level 2 of the fair value hierarchy (including the reasons for these transfers) and the reasons for any transfers in or out of Level 3.  It also requires a reconciliation of recurring Level 3 measurements including purchases, sales and issuances and settlements on a gross basis.  The accounting update clarifies certain existing disclosure requirements and provides fair value measurement disclosures for each class of assets and liabilities as opposed to each major category of assets and liabilities.  It also clarifies that entities are required to disclose information about both the valuation techniques and inputs used in estimating Level 2 and Level 3 fair value measurements.  Except for the disclosures on the reconciliation of recurring Level 3 measurements, the other new disclosures and clarifications of existing disclosures were effective for us beginning with the first quarter of our 2010 fiscal year.  The adoption of this standard did not have a material impact on our condensed consolidated financial statements.  See Note 8, “Fair Values of Debt Instruments, Short-Term Investments and Derivative Instruments” for our fair value measurement disclosure.  The information about the activity in Level 3 fair value measurements on a gross basis will be effective for us beginning with the first quarter of our 2011 fiscal year.  We are currently in the process of evaluating the impact on our consolidated financial statements from the adoption of this portion of the standard.
 
NOTE 3.  EARNINGS PER SHARE
 
In our computation of diluted earnings per share (“EPS”), we exclude the potential shares related to stock options that are issued and unexercised where the exercise price exceeds the average market price of our common stock during the period.  We also exclude nonvested restricted stock awards and units that have an anti-dilutive effect on EPS or that currently have not met performance conditions.
 
The following table summarizes the components of weighted-average common shares outstanding for both basic and diluted EPS:
 
   
Three Months Ended
 
(In thousands, except per share data)
 
April 2,
2010
   
April 3,
2009
 
Weighted-average common stock shares outstanding (1) 
    81,384       81,492  
Effect of dilutive stock options, restricted stock awards and units and employee stock purchase plan shares
    528       526  
Weighted-average common stock outstanding – Diluted
    81,912       82,018  

(1)  
Weighted-average common stock outstanding is net of treasury stock.
 
(In thousands)
 
April 2,
2010
   
April 3,
2009
 
Anti-dilutive equity awards not included above
    69       535  
 
NOTE 4.  ACCOUNTS RECEIVABLE AND COSTS AND ACCRUED EARNINGS IN EXCESS OF BILLINGS ON CONTRACTS
 
Accounts receivable in the accompanying Condensed Consolidated Balance Sheets are primarily comprised of amounts billed to clients for services already provided, but which have not yet been collected.  Occasionally, under the terms of specific contracts, we are permitted to submit invoices in advance of providing our services to our clients and to the extent they have not been collected, these amounts are also included in accounts receivable.
 

11

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


Costs and accrued earnings in excess of billings on contracts in the accompanying Condensed Consolidated Balance Sheets represent unbilled amounts earned and reimbursable under contracts.  As of April 2, 2010 and January 1, 2010, costs and accrued earnings in excess of billings on contracts were $1.21 billion and $1.02 billion, respectively.  These amounts become billable according to the contract terms, which usually consider the passage of time, achievement of milestones or completion of the project.  Generally, such unbilled amounts will be billed and collected over the next twelve months.
 
Accounts receivable and costs and accrued earnings in excess of billings on contracts include certain amounts recognized related to unapproved change orders (amounts representing the value of proposed contract modifications, but which are unapproved as to both price and scope) and claims, (amounts in excess of agreed contract prices that we seek to collect from our clients or others) that have not been collected and, in the case of balances included in accrued earnings in excess of billings on contracts, may not be billable until an agreement, or in the case of claims, a settlement is reached.  Most of those balances are not material and are typically resolved in the ordinary course of business.  At April 2, 2010, significant unapproved change orders and claims collectively represented approximately 4% of our accounts receivable and accrued earnings in excess of billings on contracts.
 
The following table summarizes the components of our accounts receivable and costs and accrued earnings in excess of billings on contracts with the U.S. federal government and with other customers as of April 2, 2010 and January 1, 2010.
 
   
As of
 
(In millions)
 
April 2,
2010
   
January 1,
2010
 
Accounts receivable:
           
U.S. federal government
  $ 366.1     $ 330.5  
Others
    644.1       593.8  
Total accounts receivable
  $ 1,010.2     $ 924.3  
Costs and accrued earnings in excess of billings on contracts:
               
U.S. federal government
  $ 711.9     $ 557.7  
Others
    493.8       466.5  
Total costs and accrued earnings in excess of billings on contracts
  $ 1,205.7     $ 1,024.2  

NOTE 5.  JOINT VENTURES
 
The nature of our involvement in our consolidated and unconsolidated joint ventures includes providing the following:
 
·  
Design, engineering, construction and construction management services relating to specific technology involving flue gas desulfurization processes;
 
·  
Construction management services, including pre-construction services, procurement of materials and small equipment, installation of owner-furnished equipment, and construction of a cement manufacturing facility;
 
·  
Engineering, procurement and construction of a concrete dam;
 
·  
Liquid waste management services, including the decontamination of a former nuclear fuel reprocessing facility and nuclear hazardous waste processing;
 
·  
Management of ongoing tank cleanup effort, including retrieving, treating, storing and disposing of nuclear waste that is stored at tank farms; and
 

12

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


·  
Management and operation services, including commercial operations, decontamination, decommissioning, and waste management of a low-level nuclear waste repository in the United Kingdom (“U.K.”).
 
In accordance with current consolidation standards, we analyzed all of our joint ventures and classified them into two groups:
 
·  
Joint ventures that should be consolidated because we hold the majority voting interest or because they are VIEs and we are the primary beneficiary; and
 
·  
Joint ventures, which are VIEs, but we are not the primary beneficiary or joint ventures, which are not VIEs and we hold a minority voting interest, and therefore do not need to be consolidated.
 
Our review of our joint ventures resulted in the identification and consolidation of several immaterial joint ventures, which, under the previous standard, should have been consolidated.
 
We aggregated financial information relating to our VIEs because their nature and risk and reward characteristics are similar.  None of our current joint ventures that meet the characteristics of a VIE are individually significant to our consolidated financial statements.
 
Consolidated Joint Ventures
 
The following table presents the total assets and liabilities of our consolidated joint ventures:
 
(In thousands)
 
April 2,
2010
   
January 1,
2010
 
Cash and cash equivalents                                                            
  $ 138,007     $ 112,424  
Net accounts receivable                                                            
    379,031       228,132  
Other current assets                                                            
    5,420       2,200  
Non-current assets                                                            
    38,833       197  
Total assets                                                  
  $ 561,291     $ 342,953  
                 
Accounts and subcontractors payable                                                            
  $ 218,827     $ 128,073  
Billings in excess of costs and accrued earnings
    17,347       14,589  
Accrued expenses and other                                                            
    31,554       31,416  
Non-current liabilities                                                            
    2,676        
Total liabilities                                                     
    270,404       174,078  
                 
Total URS equity                                                            
    185,377       124,224  
Noncontrolling interests                                                            
    105,510       44,651  
Total owners’ equity                                                     
    290,887       168,875  
Total liabilities and owners’ equity
  $ 561,291     $ 342,953  

Total revenues of the consolidated ventures were $364.1 million and $328.2 million for the three months ended April 2, 2010 and April 3, 2009, respectively.
 
For the three months ended April 2, 2010 and April 3, 2009, there were no material changes in our ownership interests in our consolidated joint ventures.  In addition, we have immaterial amounts of other comprehensive income attributable to the noncontrolling interests.
 

13

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


Unconsolidated Joint Ventures
 
We use the equity method of accounting for our unconsolidated joint ventures.  Under the equity method, we recognize our proportionate share of the net earnings of these joint ventures as a single line item under “Equity in income of unconsolidated joint ventures” in our Condensed Consolidated Statement of Operations.
 
The table below presents financial information, derived from the most recent financial statements provided to us, on a combined 100% basis for our unconsolidated joint ventures:
 
(In thousands)
 
Unconsolidated VIEs (1)
   
MIBRAG Mining Joint Venture (2)
 
April 2, 2010
           
Current assets
  $ 425,614       N/A  
Noncurrent assets
  $ 8,819       N/A  
Current liabilities
  $ 278,914       N/A  
Noncurrent liabilities
  $ 9,300       N/A  
                 
January 1, 2010
               
Current assets
  $ 574,556       N/A  
Noncurrent assets
  $ 18,275       N/A  
Current liabilities
  $ 442,688       N/A  
Noncurrent liabilities
  $ 84       N/A  
                 
Three months ended April 2, 2010 (1)
               
Revenues
  $ 324,669       N/A  
Cost of revenues
    (270,141 )     N/A  
Income from continuing operations before tax
  $ 54,528       N/A  
Net income
  $ 49,745       N/A  
                 
Three months ended April 3, 2009
               
Revenues
  $ 562,045     $ 134,177  
Cost of revenues
    (492,223 )     (103,485 )
Income from continuing operations before tax
  $ 69,822     $ 30,692  
Net income
  $ 67,563     $ 30,332  

(1)  
Income from unconsolidated U.S. joint ventures is generally not taxable in most tax jurisdictions in the United States.  The tax expenses on our other unconsolidated joint ventures are primarily related to foreign taxes.
 
 
(2)  
During the second quarter of 2009, we sold our equity investment in the MIBRAG mbH (“MIBRAG”) mining venture.
 
 
There were no distributions from MIBRAG for the three months ended April 2, 2010 and April 3, 2009.  We received $17.3 million and $22.9 million, respectively, of distributions from other unconsolidated joint ventures for the three months ended April 2, 2010 and April 3, 2009.
 

14

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


Maximum Exposure to Loss
 
In addition to potential losses arising out of the carrying values of the assets and liabilities of our unconsolidated joint ventures, our maximum exposure to loss also includes performance assurances and guarantees we sometimes provide to clients on behalf of joint ventures that we do not directly control.  We enter into these guarantees primarily to support the contractual obligations associated with these joint projects.  The potential payment amount of an outstanding performance guarantee is typically the remaining cost of work to be performed by or on behalf of third parties under engineering and construction contracts.  However, the nature of these costs are such that we are not able to estimate amounts that may be required to be paid in excess of estimated costs to complete contracts and, accordingly, the exposure to loss as a result of these performance guarantees cannot be calculated.
 
NOTE 6.  PROPERTY AND EQUIPMENT
 
Our property and equipment consisted of the following:
 
(In thousands)
 
April 2,
2010
   
January 1,
2010
 
Equipment and internal-use software
  $ 380,994     $ 376,169  
Construction and mining equipment
    123,191       115,954  
Furniture and fixtures
    56,933       57,038  
Leasehold improvements
    70,918       71,037  
Construction in progress
    132       130  
Land and improvements
    584       584  
      632,752       620,912  
Accumulated depreciation and amortization
    (384,820 )     (361,962 )
Property and equipment at cost, net
  $ 247,932     $ 258,950  
 
Our depreciation expense related to property and equipment was $19.8 million and $22.7 million for the three months ended April 2, 2010 and April 3, 2009, respectively.
 
Intangible Assets
 
Amortization expense related to intangible assets was $11.1 million and $13.2 million for the three months ended April 2, 2010 and April 3, 2009, respectively.
 
NOTE 7.  INDEBTEDNESS
 
Indebtedness consisted of the following:
 
(In thousands)
 
April 2,
2010
   
January 1,
2010
 
Bank term loans, net of debt issuance costs
  $ 766,119     $ 763,858  
Obligations under capital leases
    15,136       16,481  
Notes payable, foreign credit lines and other indebtedness
    23,114       24,647  
Total indebtedness
    804,369       804,986  
Less:
               
Current portion of long-term debt
    16,337       115,261  
Long-term debt
  $ 788,032     $ 689,725  


 

15

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


2007 Credit Facility
 
As of both April 2, 2010 and January 1, 2010, the outstanding balance of term loan A was $607.6 million at interest rates of 1.29% and 1.25%, respectively.  As of both April 2, 2010 and January 1, 2010, the outstanding balance of term loan B was $167.4 million at interest rates of 2.54% and 2.50%, respectively.
 
Under the terms of our 2007 Credit Facility, we are generally required to remit as debt payments any proceeds we receive from the sale of assets and the issuance of debt.  On February 16, 2010, we entered into a consent agreement to our 2007 Credit Facility, which allows us to use the funds from the sale of our equity investment in MIBRAG for general operating purposes.  As a result of this consent, we were no longer required to remit a payment relating to this asset sale in the first quarter of 2010 and our next scheduled payment is expected to be due in December 2011.
 
Under our Senior Secured Credit Facility (“2007 Credit Facility”), we are subject to two financial covenants: 1) a maximum consolidated leverage ratio, which is calculated by dividing consolidated total debt by consolidated EBITDA, as defined below, and 2) a minimum interest coverage ratio, which is calculated by dividing consolidated cash interest expense into consolidated EBITDA.  Both calculations are based on the financial data of the most recent four fiscal quarters.
 
For purposes of our 2007 Credit Facility, consolidated EBITDA is defined as consolidated net income attributable to URS plus interest, depreciation and amortization expense, amounts set aside for taxes, other non-cash items (including goodwill impairments) and other pro forma adjustments related to permitted acquisitions and the Washington Group International (“WGI”) acquisition in 2007.
 
As of April 2, 2010, our consolidated leverage ratio was 1.3, which did not exceed the maximum consolidated leverage ratio of 2.375, and our consolidated interest coverage ratio was 17.8, which exceeded the minimum consolidated interest coverage ratio of 5.0.  During the first quarter of 2010, Moody’s Investor Services upgraded our credit rating to Ba1.  On April 16, 2010, Standard and Poor’s upgraded our credit rating to BB+.  As a result of our upgraded credit ratings, some of our non-financial covenants, such as the ability to acquire other companies, are no longer applicable or became less restrictive.  We were in compliance with the covenants of our 2007 Credit Facility as of April 2, 2010.
 
Revolving Line of Credit
 
We did not have an outstanding debt balance on our revolving line of credit as of April 2, 2010 and January 1, 2010.  As of April 2, 2010, we had issued $212.7 million of letters of credit, leaving $487.3 million available on our revolving credit facility.  If we elected to borrow the remaining amounts available under our revolving line of credit as of April 2, 2010, we would remain in compliance with the covenants of our 2007 Credit Facility.
 
 
10BOther Indebtedness
 
Notes payable, foreign credit lines and other indebtedness.  As of April 2, 2010 and January 1, 2010, we had outstanding amounts of $23.1 million and $24.6 million, respectively, in notes payable and foreign lines of credit.  Notes payable primarily include notes used to finance the purchase of office equipment, computer equipment and furniture.  The weighted-average interest rates of the notes were approximately 5.5% and 5.6% as of April 2, 2010 and January 1, 2010, respectively.
 
We maintain foreign lines of credit, which are collateralized by the assets of our foreign subsidiaries and, in some cases, parent guarantees.  As of April 2, 2010 and January 1, 2010, we had lines of credit available under these facilities of $15.8 million, with no amount outstanding.
 

16

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


Capital Leases.  As of April 2, 2010 and January 1, 2010, we had obligations under our capital leases of approximately $15.1 million and $16.5 million, respectively, consisting primarily of leases for office equipment, computer equipment and furniture.
 
NOTE 8.  FAIR VALUES OF DEBT INSTRUMENTS, SHORT-TERM INVESTMENTS AND DERIVATIVE INSTRUMENTS
 
Our short-term investments and derivative instruments, which consist of our interest rate swaps, were carried at their fair values as of April 2, 2010 and January 1, 2010, as presented in the following tables:
 
(In millions)
Total
Carrying
Value as of
April 2,
2010
   
Fair Value Measurement as of April 2, 2010
 
   
Quoted Prices in
Active Markets
(Level 1)
   
Significant Other Observable Inputs
(Level 2)
   
Significant Unobservable
Inputs
(Level 3)
 
Interest rate swap liability
        5.6
    $
       —
    $
         5.6
    $
        —
 
Short-term investments
0.6
   
   
0.6
   
 
 
(In millions)
Total
Carrying
Value as of
January 1,
2010
   
Fair Value Measurement as of January 1, 2010
 
   
Quoted Prices in
Active Markets
(Level 1)
   
Significant Other Observable Inputs
(Level 2)
   
Significant Unobservable
Inputs
(Level 3)
 
Interest rate swap liability
        7.1
    $
       —
    $
         7.1
    $
        —
 
Short-term investments
30.7
   
   
30.7
   
 
 
2007 Credit Facility
 
As of April 2, 2010 and January 1, 2010, the estimated current market values of term loans A and B, net of debt issuance costs, were approximately $6.1 million and $25.3 million less than the amount reported on our Condensed Consolidated Balance Sheets, respectively.  The fair values of our term loans A and B were derived by taking the mid-point of the trading prices from an observable market input in the secondary loan market and multiplying it by the outstanding balance of our term loans.  The change in the fair values of our loans from January 1, 2010 to April 2, 2010 was due to the improvement in the financial markets and a credit rating upgrade by an outside credit rating agency.  
 
Interest Rate Swap
 
Our 2007 Credit Facility is a floating-rate facility.  To hedge against changes in floating interest rates, we have one floating-for-fixed interest rate swap with a notional amount of $200.0 million, maturing on December 31, 2010.  As of April 2, 2010 and January 1, 2010, the fair value of our swap liability was $5.6 million and $7.1 million, respectively.  The swap liability was recorded in “Other current liabilities” on our Condensed Consolidated Balance Sheets.  The adjustments to the fair value of the swap liability were recorded in “Accumulated other comprehensive loss.”  We have recorded no gain or loss on our Condensed Consolidated Statements of Operations as our interest rate swap is an effective hedge.
 

17

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


We use our derivative instruments as a risk management tool and not for trading or speculative purposes.  The fair value of each derivative instrument is based on mark-to-model measurements that are interpolated from observable market data as of April 2, 2010 and January 1, 2010 and for the duration of each derivative’s terms.  The fair values of our short-term investments, consisting of interest-bearing time deposits, approximate their carrying values based upon the current market rates for similar instruments.
 
Foreign Currency Forward Contract
 
On March 4, 2009, we entered into a foreign currency forward contract with a notional amount of €196.0 million (equivalent to U.S. $246.1 million per the contract) with a maturity window from April 15, 2009 to July 31, 2009.  The primary objective of the contract was to manage our exposure to foreign currency transaction risk related to the Euro proceeds we received from the sale of our equity investment in MIBRAG, which closed on June 10, 2009.  We designated €128.0 million (equivalent to U.S. $160.7 million at the contractual rate) of the contract as a hedge of our net investment in MIBRAG.
 
For the three months ended April 3, 2009, we recorded a $6.2 million unrealized loss on the foreign currency forward contract in “Other expenses” on our Condensed Consolidated Statements of Operations.  We settled our foreign currency forward contract during the second quarter of 2009.
 
NOTE 9.  BILLINGS IN EXCESS OF COSTS AND ACCRUED EARNINGS ON CONTRACTS
 
Billings in excess of costs and accrued earnings on contracts in the accompanying Condensed Consolidated Balance Sheets consist of cash collected from clients and billings to clients on contracts in advance of work performed, advance payments negotiated as a contract condition, estimated losses on uncompleted contracts, normal profit liabilities, project-related legal liabilities, and other project-related reserves.  The majority of the unearned project-related costs will be earned over the next twelve months.
 
The following table summarizes the components of billings in excess of costs and accrued earnings on contracts:
 
   
As of
 
(In millions)
 
April 2,
2010
   
January 1,
2010
 
Billings in excess of costs and accrued earnings on contracts
  $ 179.9     $ 195.6  
Advance payments negotiated as a contract condition
    10.6       10.1  
Estimated losses on uncompleted contracts
    10.9       19.0  
Normal profit liabilities
    0.4       0.4  
Project-related legal liabilities and other project-related reserves
    6.3       5.9  
Other
    4.5       4.3  
Total
  $ 212.6     $ 235.3  


18

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)

 
NOTE 10.  INCOME TAXES
 
Our effective income tax rates for the three months ended April 2, 2010 and April 3, 2009 were 1.9% and 41.0%, respectively.  The reduction in the rate was primarily due to our determination made during the first quarter of 2010 that earnings of all of our foreign subsidiaries will be indefinitely reinvested offshore, which resulted in the reversal of the net U.S. deferred tax liability on the undistributed earnings of all foreign subsidiaries.  On February 16, 2010, we entered into a consent with our lenders related to our 2007 Credit Facility that permits us to utilize the funds received in June 2009 from the sale of our equity investment in MIBRAG for general operating purposes.  This consent allows these funds to be indefinitely reinvested offshore as part of our strategy to expand our international business.  During the three months ended April 2, 2010, we further developed this strategy from the indefinite reinvestment of the earnings of a single foreign subsidiary to the indefinite reinvestment of the earnings of all of our foreign subsidiaries.
 
   
April 2, 2010
   
April 3, 2009
 
   
Amount
   
Tax Rate
   
Amount
   
Tax Rate
 
U.S. statutory rate applied to income before taxes
  $ 40,547       35.0 %   $ 49,292       35.0 %
State taxes, net of federal benefit
    5,298       4.6       6,508       4.6  
Change in indefinite reinvestment assertion
    (61,097 )     (52.7 )            
Adjustments to valuation allowances
    8,811       7.6              
Adjustments related to changing foreign tax credits to deductions
    13,616       11.8              
Foreign income taxed at rates other than 35%
    (4,686 )     (4.1 )     89        
Other adjustments
    (307 )     (0.3 )     1,746       1.4  
Total income tax expense
  $ 2,182       1.9 %   $ 57,635       41.0 %

As of April 2, 2010, our federal net operating loss (“NOL”) carryover was approximately $22.2 million.  These federal NOL carryovers expire in years 2020 through 2025.  In addition to the federal NOL carryovers, there are also state income tax NOL carryovers in various taxing jurisdictions of approximately $423.7 million.  These state NOL carryovers expire in years 2010 through 2027.  There are also foreign NOL carryovers in various taxing jurisdictions of approximately $306.2 million.  The majority of the foreign NOL carryovers have no expiration date.  The NOL carryovers result in a deferred tax asset of $110.5 million.  A valuation allowance of $86.8 million has been established against these deferred tax assets.  None of the remaining deferred tax assets related to NOL carryovers is individually material.  Full recovery of our NOL carryovers will require that the appropriate legal entity generate taxable income in the future at least equal to the amount of the NOL carryovers within the applicable taxing jurisdiction.
 
We anticipate that cash payments for income taxes for 2010 and later years will be substantially less than income tax expense recognized in the financial statements.  This difference results from expected tax deductions for goodwill amortization.  As of April 2, 2010, we have remaining tax-deductible goodwill of $399.8 million resulting from acquisitions by WGI before our acquisition of WGI, as well as from our other prior acquisitions.  The amortization of this goodwill is deductible over various periods ranging up to 13 years.  The tax deduction for goodwill for 2010 is expected to be $87.2 million.  The amount of the tax deduction for goodwill is expected to decrease slightly over the next four years and will be substantially lower after five years.
 

19

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


NOTE 11.  EMPLOYEE RETIREMENT AND POST-RETIREMENT BENEFIT PLANS
 
Defined Benefit Plans
 
We sponsor a number of pension and unfunded supplemental executive retirement plans.  The components of our net periodic pension costs relating to the defined benefit plans for the three months ended April 2, 2010 and April 3, 2009 were as follows:
 
   
Domestic Plans
   
Foreign Plan
 
(In thousands)
 
April 2,
2010
   
April 3,
2009
   
April 2,
2010
   
April 3,
2009
 
Service cost
  $ 1,590     $ 1,660     $     $  
Interest cost
    4,610       4,605       278       173  
Expected return on plan assets
    (3,933 )     (3,745 )     (161 )     (101 )
Amortization of:
                               
Prior service costs
    (796 )     (796 )            
Net loss
    902       246       24        
Net periodic pension cost
  $ 2,373     $ 1,970     $ 141     $ 72  
 
During the three months ended April 2, 2010, we made cash contributions, including employer-directed benefit payments, of $7.6 million to the domestic and foreign defined benefit plans.  We currently expect to make additional cash contributions, including estimated employer-directed benefit payments, of approximately $13.1 million for the remainder of 2010.
 
Post-retirement Benefit Plans
 
We sponsor a number of retiree health and life insurance benefit plans (“post-retirement benefit plans”).  The components of our net periodic benefit cost relating to the post-retirement benefit plans for the three months ended April 2, 2010 and April 3, 2009 were as follows:
 
(In thousands)
 
April 2,
2010
   
April 3,
2009
 
Service cost
  $ 17     $ 16  
Interest cost
    562       637  
Expected return on plan assets
    (63 )     (53 )
Amortization of:
               
Net gain
    (33 )     (36 )
Net periodic benefit cost
  $ 483     $ 564  
 
During the three months ended April 2, 2010, we made employer-directed benefit payments of $1.0 million to the post-retirement benefit plans.  We currently expect to make cash contributions, including estimated employer-directed benefit payments, of approximately $2.6 million for the remainder of 2010.
 

20

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


NOTE 12.  STOCKHOLDERS’ EQUITY
 
Equity Incentive Plans
 
As of April 2, 2010, approximately 1.3 million shares were issued as restricted stock awards and 0.1 million shares were issuable upon the vesting of restricted stock units under our 2008 Equity Incentive Plan (the “2008 Plan”).  In addition, approximately 3.6 million shares remained reserved for future grant under the 2008 Plan.  The 2008 Plan replaced our 1999 Equity Incentive Plan (“1999 Plan”).  Although our 1999 Plan became inactive, as of April 2, 2010, we still had approximately 0.8 million shares of nonvested restricted stock awards and restricted stock units and approximately 0.7 million shares of outstanding unexercised stock options that had been granted under the 1999 Plan.
 
Stock Repurchase Program
 
During the three months ended April 2, 2010, we repurchased an aggregate of 1.0 million shares of our common stock at an average price of $48.41 per common share for approximately $48.4 million.  During the three months ended April 3, 2009, we repurchased an aggregate of 0.6 million shares of our common stock at an average price of $37.57 per common share for approximately $24.0 million.
 
Stock-Based Compensation
 
We recognize stock-based compensation expense, net of estimated forfeitures, over the vesting periods in “General and administrative expenses” and “Cost of revenues” in our Condensed Consolidated Statements of Operations.
 
The following table presents our stock-based compensation expenses related to restricted stock awards and units, our employee stock purchase plan and the related income tax benefits recognized, for the three months ended April 2, 2010 and April 3, 2009.
 
   
Three Months Ended
 
(In millions)
 
April 2,
2010
   
April 3,
2009
 
Stock-based compensation expenses:
           
Restricted stock awards and units
  $ 10.3     $ 7.9  
Employee stock purchase plan
    0.1       0.7  
Stock-based compensation expenses
  $ 10.4     $ 8.6  
                 
Total income tax benefits recognized in our net income related to stock-based compensation expenses
  $ 4.0     $ 3.3  
 
Employee Stock Purchase Plan
 
Our 2008 Employee Stock Purchase Plan allows qualifying employees to purchase shares of our common stock through payroll deductions of up to 10% of their compensation, subject to Internal Revenue Code limitations, at a price of 95% of the fair market value as of the end of each of the six-month offering periods.  The offering periods commence on January 1 and July 1 of each year.
 

21

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


 
Restricted Stock Awards and Units
 
Restricted stock awards and units generally vest over a four-year vesting period.  Vesting of some awards is subject to both service requirements and performance conditions.  Restricted stock awards and units with a performance condition vest upon achievement of an annual net income target, established in the first quarter of the fiscal year preceding the vesting date.  Our awards are measured based on the stock price on the date that all of the key terms and conditions related to the award are known and are expensed over their respective vesting periods.  Restricted stock awards and restricted stock units are expensed on a straight-line basis over their respective vesting periods subject to the probability of meeting performance and/or service requirements.
 
As of April 2, 2010, we had estimated unrecognized stock-based compensation expense of $78.0 million related to nonvested restricted stock awards and units.  This expense is expected to be recognized over a weighted-average period of 2.4 years.  The following table summarizes the total fair values of vested shares, according to their contractual terms, and the grant date fair values of restricted stock awards and units granted during the three months ended April 2, 2010 and April 3, 2009:
 
(In millions)
 
April 2,
2010
   
April 3,
2009
 
Fair values of shares vested
  $ 33.8     $ 12.2  
Grant date fair values of restricted stock awards and units granted
  $ 0.3     $ 0.6  
 
A summary of the status of and changes in our nonvested restricted stock awards and units, according to their contractual terms, as of and for the three months ended April 2, 2010 is presented below:
 
   
Three Months Ended
April 2, 2010
 
   
Shares
   
Weighted-Average Grant Date Fair Value
 
Nonvested at January 1, 2010
    2,644,571     $ 42.16  
Granted
    5,880     $ 44.52  
Vested
    (833,427 )   $ 40.55  
Forfeited
    (26,377 )   $ 40.65  
Nonvested at April 2, 2010
    1,790,647     $ 42.94  
 
Stock Options
 
We have not granted any stock options since September 2005.  Stock options expire in ten years from the date of grant.  A summary of the status and changes of the stock options, according to their contractual terms, is presented below:
 
   
Options
   
Weighted-Average Exercise Price
   
Weighted-Average Remaining Contractual Term (in years)
   
Aggregate Intrinsic Value (in millions)
 
Outstanding and exercisable at January 1, 2010
    766,066     $ 22.99       3.46     $ 16.5  
Exercised
    (50,530 )   $ 21.92                  
Forfeited/expired/cancelled
        $ 0.00                  
Outstanding and exercisable at April 2, 2010
    715,536     $ 23.06       3.26     $ 19.4  

22

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


The aggregate intrinsic value in the preceding table represents the total pre-tax intrinsic value, based on our closing market price of $50.23 as of April 2, 2010, which would have been received by the option holders had all option holders exercised their options on that date.
 
For the three months ended April 2, 2010 and April 3, 2009, the aggregate intrinsic value of stock options exercised, determined as of the date of option exercise, was $1.3 million and $0.7 million, respectively.  Since all of our stock option awards were fully vested in fiscal year 2008, we did not have any stock-based compensation expense related to stock option awards nor any unrecognized related expense.
 
NOTE 13.  SEGMENT AND RELATED INFORMATION
 
We operate our business through the following three segments:
 
·  
Infrastructure & Environment business (formerly referred to as the URS Division) provides a comprehensive range of professional program management, planning, design, engineering, construction and construction management, operations and maintenance, and decommissioning and closure services to the U.S. federal government, state and local government agencies, and private sector clients in the U.S. and internationally.
 
·  
Federal Services business (formerly referred to as the EG&G Division) provides services to various U.S. federal government agencies, primarily the Departments of Defense and Homeland Security.  These services include program management, planning, design and engineering, systems engineering and technical assistance, construction and construction management, operations and maintenance, and decommissioning and closure.
 
·  
Energy & Construction business (formerly referred to as the Washington Division) provides program management, planning, design, engineering, construction and construction management, operations and maintenance, and decommissioning and closure services to the U.S. federal government, state and local government agencies, and private sector clients in the U.S. and internationally.
 
These three segments operate under separate management groups and produce discrete financial information.  Their operating results also are reviewed separately by management.  The accounting policies of the reportable segments are the same as those described in the summary of significant accounting policies in our Annual Report on Form 10-K for the year ended January 1, 2010.  The information disclosed in our condensed consolidated financial statements is based on the three segments that comprise our current organizational structure.
 

23

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


The following tables present summarized financial information for our reportable segments.  “Inter-segment, eliminations and other” in the following tables include elimination of inter-segment sales and investments in subsidiaries.  The segment balance sheet information presented below is included for informational purposes only.  We do not allocate resources based upon the balance sheet amounts of individual segments.  Our long-lived assets consist primarily of property and equipment.
 
   
Three Months Ended
 
(In millions)
 
April 2,
2010
   
April 3,
2009
 
Revenues
           
Infrastructure & Environment
  $ 775.1     $ 831.6  
Federal Services
    637.5       634.4  
Energy & Construction
    808.1       1,073.3  
Inter-segment, eliminations and other
    (13.2 )     (18.7 )
Total revenues
  $ 2,207.5     $ 2,520.6  
Equity in income of unconsolidated joint ventures
               
Infrastructure & Environment
  $ 0.9     $ 2.6  
Federal Services
    1.5       1.9  
Energy & Construction
    22.3       35.5  
Total equity in income of unconsolidated joint ventures
  $ 24.7     $ 40.0  
Contribution (1)
               
Infrastructure & Environment
  $ 54.0     $ 66.1  
Federal Services
    41.2       40.6  
Energy & Construction
    44.8       80.2  
General and administrative expenses (2) 
    (25.5 )     (23.4 )
Total contribution
  $ 114.5     $ 163.5  
Operating income
               
Infrastructure & Environment
  $ 51.4     $ 63.5  
Federal Services
    35.7       35.9  
Energy & Construction
    58.4       81.8  
General and administrative expenses
    (20.3 )     (18.1 )
Total operating income
  $ 125.2     $ 163.1  
Depreciation and amortization
               
Infrastructure & Environment
  $ 8.7     $ 8.5  
Federal Services
    5.3       5.7  
Energy & Construction
    15.2       19.9  
Corporate and other
    1.8       1.8  
Total depreciation and amortization
  $ 31.0     $ 35.9  

(1)  
We are providing segment contribution because management uses this information to assess performance and make decisions about resource allocation.  We define segment contribution as total segment operating income minus noncontrolling interests attributable to that segment, but before allocation of various segment expenses, including stock compensation expenses, impairment of intangible assets, amortization of intangible assets, and other miscellaneous unallocated expenses.  Segment operating income represents net income before reductions for income taxes, noncontrolling interests and interest expense.
 
 
(2)  
General and administrative expenses represent expenses related to corporate functions.
 
 

 

24

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


A reconciliation of segment contribution to segment operating income for the three months ended April 2, 2010 and April 3, 2009 is as follows:
 
   
Three Months Ended April 2, 2010
 
(In millions)
 
Infrastructure
&
Environment
   
Federal
Services
   
Energy
&
Construction
   
Corporate
   
Consolidated
 
Contribution
  $ 54.0     $ 41.2     $ 44.8     $ (25.5 )   $ 114.5  
Noncontrolling interests
    1.1             23.2             24.3  
Amortization of intangible assets
    (0.1 )     (4.0 )     (7.0 )           (11.1 )
Stock-based compensation expenses
    (3.6 )     (1.3 )     (3.1 )     8.0        
Other miscellaneous unallocated expenses
          (0.2 )     0.5       (2.8 )     (2.5 )
Operating income (loss)
  $ 51.4     $ 35.7     $ 58.4     $ (20.3 )   $ 125.2  
                                         
   
Three Months Ended April 3, 2009
 
(In millions)
 
Infrastructure
&
Environment
   
Federal
Services
   
Energy
&
Construction
   
Corporate
   
Consolidated
 
Contribution
  $ 66.1     $ 40.6     $ 80.2     $ (23.4 )   $ 163.5  
Noncontrolling interests
    0.6             12.3             12.9  
Amortization of intangible assets
    (0.1 )     (4.2 )     (8.9 )           (13.2 )
Stock-based compensation expenses
    (3.0 )     (0.5 )     (1.7 )     5.2        
Other miscellaneous unallocated expenses
    (0.1 )           (0.1 )     0.1       (0.1 )
Operating income (loss)
  $ 63.5     $ 35.9     $ 81.8     $ (18.1 )   $ 163.1  
 
Total investments in and advances to unconsolidated joint ventures and property and equipment, net of accumulated depreciation, are as follows:
 
(In millions)
 
April 2, 2010
   
January 1, 2010
 
Infrastructure & Environment
  $ 7.0     $ 7.4  
Federal Services
    3.4       4.8  
Energy & Construction
    87.1       81.7  
Total investments in and advances to unconsolidated joint ventures
  $ 97.5     $ 93.9  
                 
Infrastructure & Environment
  $ 102.1     $ 114.3  
Federal Services
    30.6       31.1  
Energy & Construction
    98.3       103.0  
Corporate
    16.9       10.6  
Total property and equipment, net of accumulated depreciation
  $ 247.9     $ 259.0  
 

 

25

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)

 
Total assets by segment are as follows:
 
(In millions)
 
April 2, 2010
   
January 1, 2010
 
Infrastructure & Environment
  $ 1,685.6     $ 1,654.3  
Federal Services
    1,553.1       1,505.3  
Energy & Construction
    3,593.6       3,616.7  
Corporate
    5,637.3       5,377.7  
Eliminations
    (5,454.7 )     (5,249.6 )
Total assets
  $ 7,014.9     $ 6,904.4  

Geographic Areas
 
Our revenues, and property and equipment at cost, net of accumulated depreciation, by geographic areas are shown below.
 
   
Three Months Ended
 
(In millions)
 
April 2,
2010
   
April 3,
2009
 
Revenues
           
United States
  $ 2,047.0     $ 2,320.7  
International
    164.3       203.2  
Eliminations
    (3.8 )     (3.3 )
Total revenues
  $ 2,207.5     $ 2,520.6  

No individual foreign country contributed more than 10% of our consolidated revenues for the three months ended April 2, 2010 and April 3, 2009.
 
(In millions)
 
April 2,
2010
   
January 1,
2010
 
Property and equipment at cost, net
           
United States
  $ 211.7     $ 220.1  
International                                                         
    36.2       38.9  
Total property and equipment at cost, net
  $ 247.9     $ 259.0  
 
There are no material concentrations of our net property and equipment in any individual foreign country.
 
Major Customers and Other
 
Our largest clients are from our federal market sector.  Within this sector, we have multiple contracts with the U.S. Army, our largest customer, which contributed 21% of our consolidated revenues for the three months ended April 2, 2010.  We also have multiple contracts with the Department of Energy (“DOE”), which contributed 12% of our consolidated revenues for the three months ended April 2, 2010.  The loss of the federal government, the U.S. Army or DOE, as clients, would have a material adverse effect on our business; however, we are not dependent on any single contract on an ongoing basis, and we believe that the loss of any contract would not have a material adverse effect on our business.
 

26

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


For purposes of analyzing revenues from major customers, we do not consider the combination of all federal departments and agencies as one customer although, in the aggregate, the federal market sector contributed 49% of our consolidated revenues for the three months ended April 2, 2010.  The different federal agencies manage separate budgets.  As such, reductions in spending by one federal agency do not affect the revenues we could earn from another federal agency.  In addition, the procurement processes for separate federal agencies are not centralized and the procurement decisions are made separately by each federal agency.
 
Our revenues from the U.S. Army and DOE for the three months ended April 2, 2010 and April 3, 2009 are presented below:
 
   
Three Months Ended
 
(In millions)
 
April 2,
2010
   
April 3,
2009
 
The U.S. Army (1)
           
Infrastructure & Environment
  $ 40.0     $ 33.8  
Federal Services
    347.7       354.0  
Energy & Construction
    77.6       21.7  
Total U.S. Army
  $ 465.3     $ 409.5  
                 
DOE
               
Infrastructure & Environment
  $ 1.1     $ 3.0  
Federal Services
    6.6       11.8  
Energy & Construction
    245.3       128.7  
Total DOE
  $ 253.0     $ 143.5  

(1)  
The U.S. Army includes U.S. Army Corps of Engineers.
 
 
NOTE 14.  COMMITMENTS AND CONTINGENCIES
 
In the ordinary course of business, we are subject to contractual guarantees and governmental audits or investigations.  We are also involved in various legal proceedings that are pending against us and our affiliates alleging, among other things, breach of contract or tort in connection with the performance of professional services, the various outcomes of which cannot be predicted with certainty.  We are including information regarding the following significant proceedings in particular:
 
·  
Minneapolis Bridge:  On August 1, 2007, the I-35W Bridge in Minneapolis, Minnesota collapsed resulting in 13 deaths, numerous injuries and substantial property loss.  In 2003, the Minnesota Department of Transportation retained URS Corporation (Nevada), our wholly owned subsidiary, to provide specific engineering analyses of components of the I-35W Bridge.  URS Corporation (Nevada) issued draft reports pursuant to this engagement.  URS Corporation (Nevada)’s services to the Minnesota Department of Transportation were ongoing at the time of the collapse.  The National Transportation Safety Board final report on the bridge collapse determined that the probable cause of the collapse was inadequate load capacity due to an error by the original bridge designer that resulted in gusset plate failures resulting from the increased bridge weight from previous modifications as well as increased traffic and concentrated construction loads on the bridge on the day of the collapse.  URS Corporation (Nevada) was not involved in the original design or construction of the I-35W Bridge, nor was it involved in any of the maintenance and construction work being performed on the bridge when the collapse occurred.
 

27

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)

 
  
A total of 121 lawsuits are currently pending against URS Corporation (Nevada) and other defendants in Hennepin County District Court in Minnesota.  The cases include the claims of 137 injured people, the estates of 11 of the individuals who died as a result of the bridge collapse, and one separate suit for insurance subrogation.  In March 2010, URS Corporation (Nevada) settled the lawsuit initiated by the State of Minnesota by agreeing to pay $5 million to the State of Minnesota.  The remaining lawsuits assert a variety of claims against URS Corporation (Nevada) including:  professional negligence, breach of contract, subrogation, statutory reimbursement, contribution and indemnity.  Insurers have also raised subrogation claims for intervention in 38 of the individual lawsuits.
 
  
We intend to continue to defend these matters vigorously; however, we cannot provide assurance that we will be successful in these efforts.  The potential range of loss and the resolution of these matters cannot be determined at this time.
 
·  
USAID Egyptian Projects:  In March 2003, WGI, the parent company acquired by us on November 15, 2007 and subsequently renamed URS E&C Holdings, Inc., was notified by the Department of Justice that the federal government was considering civil litigation against WGI for potential violations of the U.S. Agency for International Development (“USAID”) source, origin, and nationality regulations in connection with five of WGI’s USAID-financed host-country projects located in Egypt beginning in the early 1990s.  In November 2004, the federal government filed an action in the United States District Court for the District of Idaho against WGI and Contrack International, Inc., an Egyptian construction company, asserting violations under the Federal False Claims Act, the Federal Foreign Assistance Act of 1961, and common law theories of payment by mistake and unjust enrichment.  The federal government seeks damages and civil penalties for violations of the statutes as well as a refund of all amounts paid under the specified contracts of approximately $373.0 million.  WGI denies any liability in the action and contests the federal government’s damage allegations and its entitlement to any recovery.  All USAID projects under the contracts have been completed and are fully operational.
 
  
In March 2005, WGI filed motions in the Bankruptcy Court in Nevada and in the Idaho District Court to dismiss the federal government’s claim for failure to give appropriate notice or otherwise preserve those claims.  In August 2005, the Bankruptcy Court ruled that all federal government claims were barred in a written order.  The federal government appealed the Bankruptcy Court's order to the United States District Court for the District of Nevada.  In March 2006, the Idaho District Court stayed that action during the pendency of the federal government's appeal of the Bankruptcy Court's ruling.  In December 2006, the Nevada District Court reversed the Bankruptcy Court’s order and remanded the matter back to the Bankruptcy Court for further proceedings.  In December 2007, the federal government filed a motion in Bankruptcy Court seeking an order that the Bankruptcy Court abstain from exercising jurisdiction over this matter, which WGI opposed.  On February 15, 2008, the Bankruptcy Court denied the federal government’s motion preventing the Bankruptcy Court from exercising jurisdiction over WGI’s motion that the federal government’s claims in Idaho District Court were barred for failure to give appropriate notice or otherwise preserve those claims.  In November 2008, the Bankruptcy Court ruled that the federal government’s common law claims of unjust enrichment and payment by mistake are barred, and may not be further pursued.  WGI’s pending motion in the Bankruptcy Court covers all of the remaining federal government claims alleged in the Idaho action.
 
 
 
 

28

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)

 
  
WGI’s joint venture for one of the USAID projects brought arbitration proceedings before an arbitration tribunal in Egypt in which the joint venture asserted an affirmative claim for additional compensation for the construction of water and wastewater treatment facilities in Egypt.  The project owner, National Organization for Potable Water and Sanitary Drainage (“NOPWASD”), an Egyptian government agency, asserted in a counterclaim that by reason of alleged violations of the USAID source, origin and nationality regulations, and alleged violations of Egyptian law, WGI’s joint venture should forfeit its claim, pay damages of approximately $6.0 million and the owner’s costs of defending against the joint venture’s claims in arbitration.  WGI denied liability on NOPWASD’s counterclaim.  On April 17, 2006, the arbitration tribunal issued its award providing that the joint venture prevailed on its affirmative claims in the net amount of $8.2 million, and that NOPWASD's counterclaims were rejected.  WGI’s portion of any final award received by the joint venture would be approximately 45%.
 
  
WGI intends to continue to defend these matters vigorously and to consider its affirmative claims; however, we cannot provide assurance that we will be successful in these efforts.  The potential range of loss and the resolution of these matters cannot be determined at this time.
 
·  
New Orleans Levee Failure Class Action Litigation:  From July 1999 through May 2005, Washington Group International, Inc., an Ohio company, subsequently renamed URS Energy & Construction, Inc., (“WGI Ohio”), a wholly owned subsidiary acquired by us on November 15, 2007, performed demolition, site preparation, and environmental remediation services for the U.S. Army Corps of Engineers on the east bank of the Inner Harbor Navigation Canal (the “Industrial Canal”) in New Orleans, Louisiana.  On August 29, 2005, Hurricane Katrina devastated New Orleans.  The storm surge created by the hurricane overtopped the Industrial Canal levee and floodwall, flooding the Lower Ninth Ward and other parts of the city.

  
Since September 2005, 59 personal injury, property damage and class action lawsuits have been filed in Louisiana State and federal court naming WGI Ohio as a defendant.  Other defendants include the U.S. Army Corps of Engineers, the Board for the Orleans Parish Levee District, and its insurer, St. Paul Fire and Marine Insurance Company.  Over 1,450 hurricane-related cases, including the WGI Ohio cases, have been consolidated in the United States District Court for the Eastern District of Louisiana.  The plaintiffs claim that defendants were negligent in their design, construction and/or maintenance of the New Orleans levees.  The plaintiffs are all residents and property owners who claim to have incurred damages arising out of the breach and failure of the hurricane protection levees and floodwalls in the wake of Hurricane Katrina.  The allegation against us is that the work we performed adjacent to the Industrial Canal damaged the levee and floodwall and caused and/or contributed to breaches and flooding.  The plaintiffs allege damages of $200 billion and demand attorneys’ fees and costs.  WGI Ohio did not design, construct, repair or maintain any of the levees or the floodwalls that failed during or after Hurricane Katrina.  WGI Ohio performed the work adjacent to the Industrial Canal as a contractor for the federal government and has pursued dismissal from the lawsuits on a motion for summary judgment on the basis that government contractors are immune from liability.
 
  
On December 15, 2008, the District Court granted WGI Ohio’s motion for summary judgment to dismiss the lawsuit on the basis that we performed the work adjacent to the Industrial Canal as a contractor for the federal government and are therefore immune from liability, which was appealed by a number of the plaintiffs on April 27, 2009 to the United States Fifth Circuit Court of Appeals.
 
  
WGI Ohio intends to continue to defend these matters vigorously; however, we cannot provide assurance that we will be successful in these efforts.  The potential range of loss and the resolution of these matters cannot be determined at this time. 
 

 
29

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)

 
·  
SR-125:  WGI Ohio has a 50% interest in a joint venture that is performing a $401 million fixed-price highway and toll road project in California that is operational and has been open to traffic since November 2007.  Prior to the acquisition of WGI, WGI Ohio recorded significant losses on the project resulting largely from developer directives to perform extra work, developer-caused delays, and unilateral deductive changes related to contested developer claims, including claims for liquidated damages.  The joint venture is actively pursuing reimbursement of its losses based on claims of breach of contract, developer-directed changes, negligent acts by the developer, force majeure events and insurance occurrences.  The highway claims were initiated in the Superior Court of San Diego County (“Superior Court”) in July 2006 and the toll road claims were initiated in arbitration, under JAMS arbitration rules, in March 2006.
 
  
The developer has responded with amended counterclaims, filed in October 2009, in both the toll road arbitration and highway litigation in Superior Court alleging breach of contract, indemnity for claims brought against the developer by its fixed operating equipment contractor, and fraud.  The amended counterclaims in the two matters are duplicative to a degree, but in total aggregate more than $800 million in claimed damages.
 
  
In May 2009, a toll road arbitration panel hearing was held to determine whether the joint venture had previously waived multiple contractual claims under its agreement with the developer.  On August 5, 2009, the panel determined that the joint venture only waived approximately $14.0 million out of the $96.5 million of claims that the developer contended were previously waived under the toll road contract.  In addition, the joint venture, as the prevailing party, is entitled to an award of reasonable attorney’s fees and costs attributable to the waiver hearing, which the developer is contesting.  Hearings on the attorneys’ fees and costs issues were held in October 2009 and February 2010, and on February 15, 2010, the arbitration panel issued a $3.2 million award fee to the joint venture.
 
  
In December 2007, the joint venture initiated a government code claim in Superior Court against the California Department of Transportation (“Caltrans”) asserting that Caltrans failed to insure that the developer had a statutorily required payment bond.  The Superior Court granted judgment on the pleadings in favor of Caltrans in March 2009.  In addition, the developer and Caltrans have prevailed on motions for summary judgment on other government code claim issues (including lack of proper licensing, lack of authority to include the toll road project in a franchise agreement between the developer and the state, and the enforceability of certain contractual limitations that would not be enforceable under the government code in California).  The joint venture also recorded notices of a mechanic’s lien on the toll road properties and, on September 24, 2009, filed an action to foreclose the mechanic’s lien.  The joint venture also initiated an inverse condemnation action against Caltrans relating to the fee ownership of properties acquired by Caltrans impairing the joint venture’s mechanic’s lien rights on the toll road on July 11, 2008.
 
  
In June 2008, the developer filed a complaint, as amended, against the joint venture in the Supreme Court of New York County, New York, alleging that the joint venture breached a lender agreement associated with the highway project that impaired the enforceability of the highway project contract.  On October 1, 2008, a hearing was held on the joint venture’s motion to stay or dismiss this action and the Supreme Court of New York County has yet to issue its determination.  On August 31, 2009, Banco Bilbao Vizcaya Argentaria, S.A. (“BBVA”), the lender’s prime agent, filed a complaint on behalf of the lenders alleging breach of a lending agreement entered into during the highway and toll road contracts.  The joint venture filed a motion to dismiss the BBVA complaint on October 15, 2009.

30

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)

 
  
On March 22, 2010, the developer filed a Chapter 11 bankruptcy petition in the Bankruptcy Court for the Southern District of California that effectively stayed or suspended the joint venture’s highway litigation in Superior Court and the toll road arbitration.  On March 26, 2010, the joint venture filed a petition seeking to remove the previously filed foreclosure action regarding the mechanic’s lien on the toll road properties to the Bankruptcy Court.
 
  
Prior to our acquisition, WGI recognized substantial losses on the project through the joint venture.  As of April 2, 2010, our equity investment in the joint venture was $26 million.
 
  
The joint venture intends to defend these matters vigorously and will seek to collect all claimed amounts; however, we cannot provide assurance that the joint venture will be successful in these efforts.  The potential range of loss or gain and the resolution of these matters cannot be determined at this time.
 
·  
Common Sulfur Project:  One of our wholly owned subsidiaries, WGI – Middle East, Inc., whose parent company, WGI, was acquired by us on November 15, 2007, together with a consortium partner, have contracted under a fixed-price arrangement to engineer, procure and construct a sulfur processing facility located in Qatar.  Once completed, the sulfur processing facility will gather and process sulfur produced by new liquid natural gas processing facilities, which are also under construction.  The project has experienced cost increases and schedule delays.  The contract gives the customer the right to assess liquidated damages of approximately $25 million against the consortium if various project milestones are not met.  If liquidated damages are assessed, a significant portion may be attributable to WGI – Middle East, Inc.

  
To date, only a portion of the cost increases have been agreed to with the customer and acknowledged through executed change orders.  During the three months ended April 2, 2010, we recorded a charge to income of $0.6 million for this project, bringing the cumulative project losses to approximately $82.6 million as of April 2, 2010.  On November 25, 2009, the consortium filed a Notice of Arbitration in the U.K. for breach of contract and client-directed changes.  While the estimated losses have been recognized, the potential range of additional loss, if any, and the resolution of this matter cannot be determined at this time.
 
The resolution of outstanding claims is subject to inherent uncertainty, and it is reasonably possible that resolution of any of the above outstanding claims or legal proceedings could have a material adverse effect on us.
 
Insurance
 
Generally, our insurance program covers workers' compensation and employer's liability, general liability, automobile liability, professional errors and omissions liability, property, marine property and liability, and contractor’s pollution liability (in addition to other policies for specific projects).  Our insurance program includes deductibles or self-insured retentions for each covered claim.  In addition, our insurance policies contain exclusions and sublimits that insurance providers may use to deny or restrict coverage.  Excess liability and professional liability insurance policies provide for coverages on a “claims-made” basis, covering only claims actually made and reported during the policy period currently in effect.  Thus, if we do not continue to maintain these policies, we will have no coverage for claims made after the termination date even for claims based on events that occurred during the term of coverage.  While we intend to maintain these policies, we may be unable to maintain existing coverage levels.
 

31

URS CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS – UNAUDITED
(Continued)


Guarantee Obligations and Commitments
 
As of April 2, 2010, we had the following guarantee obligations and commitments:
 
We have guaranteed a letter of credit issued on behalf of one of our consolidated joint ventures.  The total amount of the letter of credit was $7.2 million as of April 2, 2010.
 
We have agreed to indemnify one of our joint venture partners up to $25.0 million for any potential losses, damages, and liabilities associated with lawsuits in relation to general and administrative services we provide to the joint venture.  Currently, we have not been advised of any indemnified claims under this guarantee.
 
As of April 2, 2010, the amount of the guarantee used to collateralize the credit facility of one of our U.K. operating subsidiaries and bank guarantee lines of some of our European subsidiaries was $8.0 million.
 
We also maintain a variety of commercial commitments that are generally made to support provisions of our contracts.  In addition, in the ordinary course of business, we provide letters of credit to clients and others against advance payments and to support other business arrangements.  We are required to reimburse the issuers of letters of credit for any payments they make under the letters of credit.
 
In the ordinary course of business, we may provide performance assurances and guarantees related to our services.  For example, these guarantees may include surety bonds, arrangements among our client, a surety, and us to ensure we perform our contractual obligations pursuant to our client agreement.  If our services under a guaranteed project are later determined to have resulted in a material defect or other material deficiency, then we may be responsible for monetary damages or other legal remedies.  When sufficient information about claims on guaranteed projects is available and monetary damages or other costs or losses are determined to be probable, we recognize such guarantee losses.
 

 


ITEM 2.
MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS
 
The following discussion contains, in addition to historical information, forward-looking statements that involve risks and uncertainties.  Our actual results and the timing of events could differ materially from those expressed or implied in this report.  See “URS Corporation and Subsidiaries” regarding forward-looking statements on page 1.  You should read this discussion in conjunction with:  Part II – Item 1A, “Risk Factors,” beginning on page 5555; the condensed consolidated financial statements and notes thereto contained in Part I – Item 1, “Financial Statements;” and the Consolidated Financial Statements included in our Annual Report on Form 10-K for the fiscal year ended January 1, 2010, which was previously filed with the Securities and Exchange Commission.
 
BUSINESS SUMMARY
 
We are a leading international provider of engineering, construction and technical services.  We offer a broad range of program management, planning, design, engineering, construction and construction management, operations and maintenance, and decommissioning and closure services to public agencies and private sector clients around the world.  We also are a major United States (“U.S.”) federal government contractor in the areas of systems engineering and technical assistance, and operations and maintenance.  We have more than 42,000 employees in a global network of offices and contract-specific job sites in more than 30 countries.  We provide our services through three businesses:  Infrastructure & Environment, Federal Services and Energy & Construction.
 
We generate revenues by providing fee-based professional and technical services and by executing construction and mining contracts.  Our professional and technical services are primarily labor intensive and our construction and mining projects are labor and capital intensive.  To derive income from our revenues, we must effectively manage our costs.
 
Our revenues are dependent upon our ability to attract and retain qualified and productive employees, identify business opportunities, allocate our labor resources to profitable markets, secure new contracts, execute existing contracts, and maintain existing client relationships.  Moreover, as a professional services company, the quality of the work generated by our employees is integral to our revenue generation.
 
Our cost of revenues is comprised of the compensation we pay to our employees, including fringe benefits; the cost of subcontractors, construction materials and other project-related expenses; and segment administrative, marketing, sales, bid and proposal, rental and other overhead costs.
 
We report our financial results on a consolidated basis and for our three reporting segments:  the Infrastructure & Environment business, the Federal Services business and the Energy & Construction business.
 
OVERVIEW AND BUSINESS TRENDS
 
Results for the Three Months Ended April 2, 2010
 
Consolidated revenues for the first quarter of 2010 were $2.2 billion compared with $2.5 billion during the same period in 2009, a decrease of 12.4% primarily due to lower demand in our power and industrial and commercial market sectors.  This decrease was offset by an $85.3 million increase in revenues resulting from the newly consolidated joint ventures during the first quarter of fiscal year 2010.  Net income attributable to URS increased 26.6% from $75.5 million during the first quarter of 2009 to $95.6 million for the first quarter of 2010 primarily due to reductions in our effective income tax rate, interest expense and overhead costs.  The income tax reduction was a result of our decision to indefinitely reinvest earnings generated from our international operations offshore.
 


Cash Flows and Debt
 
During the three months ended April 2, 2010, we used $66.0 million in cash from operations.  Cash flows from operations decreased by $287.3 million for the three months ended April 2, 2010 compared with the same period in 2009.  This decrease was primarily due to the timing of payments from clients on accounts receivable, a reduction in advance payments from clients as projects have completed, the timing of payroll payments relative to our fiscal quarter ends, the timing of payments to vendors, subcontractors, and joint ventures, and changes in income tax and interest payments, as well as a decrease in our operating income.
 
Our ratio of debt to total capitalization (total debt divided by the sum of debt and total stockholders’ equity) was 17% as of both January 1, 2010 and April 2, 2010.
 
Business Trends
 
Given the continuing turmoil in global financial markets and current economic uncertainty, it is difficult to predict the impact of the global recession on our business.  For the three months ended April 2, 2010, we experienced a decline in revenues compared to the same period in fiscal 2009.  We are continuing to monitor the situation carefully to determine the potential impact on our business during our 2010 fiscal year.  However, the continuing global uncertainty and challenging economic conditions may impair our ability to forecast business trends accurately.
 
We believe that our expectations regarding business trends are reasonable and are based on reasonable assumptions.  However, such forward-looking statements, by their nature, involve risks and uncertainties and, in the current economic climate, may be subject to an unusual degree of uncertainty.  You should read this discussion of business trends in conjunction with Part II, Item 1A, “Risk Factors,” of this report, which begins on page 55.
 
Power
 
We expect revenues from our power market sector to decline during the remainder of our 2010 fiscal year, compared to power revenues for our 2009 fiscal year, primarily due to the timing of new emissions control projects and the delay in some projects resulting from the economic downturn.  Many of our utility clients have completed or are in the final phases of projects that will enable them to meet a 2010 deadline for emissions reductions mandated by the Clean Air Interstate Rule (the “Rule”).  At the same time, some of our clients have commenced projects that will allow them to meet the Rule’s 2015 deadline for additional reductions in emissions, as well as state mandates.  In addition, as a result of the economic downturn and weaker demand for electricity, we expect to continue to experience the deferral of large capital improvement projects.
 
Partially offsetting this expected decline in revenues from emissions control projects, we anticipate sustained demand for engineering and construction services related to the development of new gas-fired power plants.  The current low cost of natural gas makes these facilities more cost-effective to operate, while producing fewer emissions than coal-fired power plants.  We also expect to continue providing upgrade, retrofit and modification services at existing nuclear facilities to increase generating capacity and extend the operational life of these facilities.  In addition, the current U.S. Administration has proposed increasing the size of the DOE’s nuclear loan guarantee program to approximately $54 billion to support the development of new nuclear facilities.
 
Infrastructure
 
We expect revenues from our infrastructure market sector to grow for the remainder of our 2010 fiscal year, given the need to rebuild and modernize aging infrastructure and the diversity of funding sources for infrastructure improvement programs.  Although many state governments are experiencing reductions in tax revenues and have reduced spending for key infrastructure programs, an increasing portion of our infrastructure work is being funded through a variety of other sources, such as bonds, dedicated tax measures and user fees.  State and local governments continued to raise capital for infrastructure programs by issuing bonds.  We expect bonds sold under this program will be used by states and municipalities to fund a variety of transportation and public facilities projects.
 


We also expect an increase in the number, size and scale of infrastructure projects funded by the American Recovery and Reinvestment Act (“ARRA”), which allocates approximately $65 billion in funding for the types of infrastructure programs for which we provide services, including highway, mass transit, high-speed rail and water projects.  Although ARRA funding for the types of large-scale infrastructure projects we support were not awarded as quickly as expected during the past fiscal year, the pace at which these projects are moving forward has accelerated, which we anticipate will increase demand for the engineering and construction services we provide.  In addition, Congress recently approved an extension to the Safe, Accountable, Flexible, Efficient Transportation Equity Act:  A Legacy for Users for the remainder of 2010, which is expected to provide $49 billion to states and local governments for highway and transit projects.
 
Federal
 
We expect revenues from our federal market sector to grow for the remainder of our 2010 fiscal year based on the diversification of our federal business; steady demand for the services we provide to the Department of Defense (“DOD”), the Department of Energy (“DOE”) and other federal agencies; and stable funding for the types of programs we support.  The DOD’s 2010 budget includes more than $375 billion in funding for programs that are important to our business, including operations and maintenance; research, development, test and evaluation; chemical demilitarization; and the Military Transformation Initiative.  In addition, the President has submitted a $33 billion supplemental funding request to support the deployment of an additional 30,000 troops to Afghanistan this year.  The funding includes approximately $24 billion for operations and maintenance activities, which we expect will result in increased demand for the repair, maintenance and modification work we perform under long-term DOD contracts.  In addition, the DOD’s proposed budget request for its 2011 fiscal year, which begins on October 1, 2010, contains approximately $159 billion in funding for contingency operations in the Middle East and $17 billion for the Military Construction program.
 
In addition, the DOE’s 2010 budget includes approximately $17 billion in funding for programs that support virtually all our work for the DOE.  The ARRA also allocates approximately $6 billion in funding to accelerate the cleanup of former nuclear weapons productions and testing facilities, including $1.5 billion for the five major sites where we manage operations.  Finally, we expect to continue to benefit from the diversification of our federal business.  We currently support more than 25 federal agencies, including the National Aeronautics and Space Administration (“NASA”); the Departments of Health and Human Services, Homeland Security, and Veterans Affairs; and the General Services Administration.
 
Industrial and Commercial
 
We expect to experience a decline in revenues from our industrial and commercial market sector for the remainder of our 2010 fiscal year, compared to industrial and commercial revenues for our 2009 fiscal year.  The economic downturn, tightened credit markets and fluctuations in commodity prices have resulted in reductions in spending on capital improvement projects among clients in the oil and gas, manufacturing and mining industries.  As a result, we have experienced and expect to continue to experience delays, curtailments or cancellations in new capital projects, for which we typically provide engineering, procurement and construction services.
 
For the remainder of our 2010 fiscal year, we expect fewer opportunities for growth as our clients take a cautious approach to starting large-scale capital improvement projects that require the engineering, procurement and construction services we provide.  At the same time, there are several positive developments in this market sector.  For example, several of our oil and gas clients are beginning initial planning for new and previously suspended projects, which they plan to pursue to the extent that economic conditions and capital budgets improve.  In the manufacturing sector, we are continuing to benefit from stable demand for our facilities management work as clients continue to outsource non-core functions to manage their overhead costs.  In addition, as the prices of metals and mineral resources stabilize, we expect our mining clients will accelerate mining activities and restart operations that were previously suspended, increasing demand for the services we provide to the mining industry.
 

Seasonality
 
We experience seasonal trends in our business in connection with federal holidays, such as Memorial Day, Independence Day, Labor Day, Thanksgiving, Christmas and New Year’s Day.  Our revenues are typically lower during these times of the year because many of our clients’ employees, as well as our own employees, do not work during these holidays, resulting in fewer billable hours charged to projects and thus, lower revenues recognized.  In addition to holidays, our business also is affected by seasonal bad weather conditions, such as hurricanes, floods, snowstorms or other inclement weather, which may cause some of our offices and projects to close or reduce activities temporarily.  For example, in the first quarter of our 2010 fiscal year, severe winter weather resulted in intermittent office closures and work interruptions for some of our operations on the East Coast, in the Midwest and in several southern states.  Severe weather conditions also caused office closures and work interruptions for offices in the United Kingdom (“U.K.”), Ireland and continental Europe.
 
Other Business Trends
 
The diversification of our business and changes in the mix and timing of our fixed-cost, target-price and other contracts can cause earnings and profit margins to vary between periods.  For example, we are experiencing an increase in the number of fixed-price contracts, particularly among clients in the federal sector.  The increase in fixed-price contracting creates both additional risks and opportunities for achieving higher margins or losses on these contracts.  In addition, earnings recognition on many contracts is measured based on progress achieved as a percentage of the total project effort or upon the completion of milestones or performance criteria rather than evenly or linearly over the period of performance.
 
The U.S. federal government also has announced its intention to reduce the outsourcing of services to outside contractors in favor of insourcing jobs to its federal employees and we expect that some of our contracts will be impacted by this decision.  While it is difficult to predict the extent to which insourcing will occur or its effect on the types of programs we support, insourcing by the current Administration could result in fewer opportunities in some components of the federal market sector.
 
We cannot determine if proposed climate change and greenhouse gas regulations would materially impact our business or our clients’ businesses at this time; however, any new regulations could impact the demand for the services we provide to our clients.  For example, we could see reduced client demand for our services related to fossil fuel and industrial projects, and increased demand for environmental, infrastructure and nuclear and alternative energy related services.
 
BOOK OF BUSINESS
 
For the purpose of calculating our book of business, we determine the amounts of all contract awards that may potentially be recognized as revenues.  We also include the equity in income of unconsolidated joint ventures over the life of the contracts.  We categorize the amount of our book of business into backlog, option years and indefinite delivery contracts (“IDCs”), based on the nature of the award and its current status.
 
As of April 2, 2010, our total book of business was $29.9 billion, a net increase of $0.5 billion, compared to $29.4 billion as of January 1, 2010.
 
Backlog.  Our contract backlog represents the monetary value of signed contracts, including task orders that have been issued and funded under IDCs and, where applicable, a notice to proceed has been received from the client that is expected to be recognized as revenues or equity in income of unconsolidated joint ventures when future services are performed.
 


The performance periods of our contracts vary widely from a few months to many years.  In addition, contract durations differ significantly among our segments, although some overlap exists.  As a result, the amount of revenues that will be realized beyond one year also varies from segment to segment.  As of January 1, 2010, we estimated that approximately 67% of our total backlog would not be realized within one year based upon the timing of awards and the long-term nature of many of our contracts; however, no assurance can be given that backlog will be realized at this rate, particularly in light of the current anticipated and continuing challenging economic environment.
 
Option Years.  Our option years represent the monetary value of option periods under existing contracts in backlog, which are exercisable at the option of our clients without requiring us to go through an additional competitive bidding process and would be canceled only if a client decides to end the project (a termination for convenience) or through a termination for default.  Option years are in addition to the “base periods” of these contracts.  Base periods for these contracts can vary from one to five years.
 
Indefinite Delivery Contracts.  IDCs represent the expected monetary value to us of signed contracts under which we perform work only when the client awards specific task orders or projects to us.  When agreements for such task orders or projects are signed and funded, we transfer their value into backlog.  Generally, the terms of these contracts exceed one year and often include a maximum term and potential value.  IDCs generally range from one to twenty years in length.
 
While the value of our book of business is a predictor of future revenues and equity in income of unconsolidated joint ventures, we have no assurance, nor can we provide assurance, that we will ultimately realize the maximum potential values for backlog, option years or IDCs.  Based on our historical experience, our backlog has the highest likelihood of converting into revenues or equity in income of unconsolidated joint ventures because it is based upon signed and executable contracts with our clients.  Option years are not as certain as backlog because our clients may decide not to exercise one or more option years.  Because we do not perform work under IDCs until specific task orders are issued by our clients, the value of our IDCs are not as likely to convert into revenues or equity in income of unconsolidated joint ventures as other categories of our book of business.
 
The following tables summarize our book of business:
 
   
As of
 
(In billions)
 
April 2,
2010
   
January 1,
2010
 
Backlog by market sector:
           
Power
  $ 1.3     $ 1.3  
Infrastructure
    2.8       2.6  
Industrial and commercial
    1.6       1.3  
Federal
    11.8       12.1  
Total backlog
  $ 17.5     $ 17.3  

(In billions)
 
Infrastructure
&
Environment
   
Federal
Services
   
Energy
&
Construction
   
Total
 
As of April 2, 2010
                       
Backlog
  $ 3.0     $ 7.3     $ 7.2     $ 17.5  
Option years
    0.5       2.1       2.1       4.7  
Indefinite delivery contracts
    5.0       1.5       1.2       7.7  
Total book of business
  $ 8.5     $ 10.9     $ 10.5     $ 29.9  
                                 
As of January 1, 2010
                               
Backlog
  $ 2.7     $ 7.2     $ 7.4     $ 17.3  
Option years
    0.4       2.1       2.5       5.0  
Indefinite delivery contracts
    4.3       1.6       1.2       7.1  
Total book of business
  $ 7.4     $ 10.9     $ 11.1     $ 29.4  


RESULTS OF OPERATIONS
 
The Three Months Ended April 2, 2010 Compared with the Three Months Ended April 3, 2009
 
Consolidated
 
   
Three Months Ended
 
(In millions, except percentages and per share amounts)
 
April 2,
2010
   
April 3,
2009
   
Increase
(Decrease)
   
Percentage
Increase
(Decrease)
 
Revenues
  $ 2,207.5     $ 2,520.6     $ (313.1 )     (12.4 %)
Cost of revenues
    (2,086.7 )     (2,379.4 )     (292.7 )     (12.3 %)
General and administrative expenses
    (20.3 )     (18.1 )     2.2       12.2 %
Equity in income of unconsolidated joint ventures
    24.7       40.0       (15.3 )     (38.3 %)
Operating income
    125.2       163.1       (37.9 )     (23.2 %)
Interest expense
    (9.3 )     (14.7 )     (5.4 )     (36.7 %)
Other expenses
          (7.6 )     (7.6 )     (100.0 %)
Income before income taxes
    115.9       140.8       (24.9 )     (17.7 %)
Income tax expense
    (2.2 )     (57.6 )     (55.4 )     (96.2 %)
Net income
    113.7       83.2       30.5       36.7 %
Noncontrolling interest in income of consolidated subsidiaries, net of tax
    (18.1 )     (7.7 )     10.4       135.1 %
Net income attributable to URS
  $ 95.6     $ 75.5     $ 20.1       26.6 %
                                 
Diluted earnings per share
  $ 1.17     $ .92     $ .25       27.2 %

The following table presents our consolidated revenues by market sector and reporting segment for the three months ended April 2, 2010 and April 3, 2009.
 
   
Three Months Ended
 
(In millions, except percentages)
 
April 2,
2010
   
April 3,
2009
   
Increase (Decrease)
   
Percentage Increase (Decrease)
 
Revenues
                       
Power sector
                       
Infrastructure & Environment
  $ 31.7     $ 47.7     $ (16.0 )     (33.5 %)
Federal Services
                       
Energy & Construction
    258.4       381.0       (122.6 )     (32.2 %)
Power Total
    290.1       428.7       (138.6 )     (32.3 %)
Infrastructure sector
                               
Infrastructure & Environment
    357.2       370.0       (12.8 )     (3.5 %)
Federal Services
                       
Energy & Construction
    114.0       77.6       36.4       46.9 %
Infrastructure Total
    471.2       447.6       23.6       5.3 %
Federal sector
                               
Infrastructure & Environment
    175.0       164.0       11.0       6.7 %
Federal Services
    636.7       633.6       3.1       0.5 %
Energy & Construction
    260.8       153.6       107.2       69.8 %
Federal Total
    1,072.5       951.2       121.3       12.8 %
Industrial and Commercial sector
                               
Infrastructure & Environment
    202.9       234.2       (31.3 )     (13.4 %)
Federal Services
                       
Energy & Construction
    170.8       458.9       (288.1 )     (62.8 %)
Industrial and Commercial Total
    373.7       693.1       (319.4 )     (46.1 %)
Total revenues, net of eliminations
  $ 2,207.5     $ 2,520.6     $ (313.1 )     (12.4 %)


Reporting Segments
 
(In millions, except percentages)
 
Revenues
   
Cost of
Revenues
   
General and Administrative Expenses
   
Equity in
Income of Unconsolidated
Joint Ventures
   
Operating
Income
 
                           
Three months ended April 2, 2010
 
 
 
 
 
 
Infrastructure & Environment
  $ 775.1     $ (724.6 )   $     $ 0.9     $ 51.4  
Federal Services
    637.5       (603.3 )           1.5       35.7  
Energy & Construction
    808.1       (772.0 )           22.3       58.4  
Eliminations
    (13.2 )     13.2                    
Corporate
                (20.3 )           (20.3 )
Total
  $ 2,207.5     $ (2,086.7 )   $ (20.3 )   $ 24.7     $ 125.2  
                                         
Three months ended April 3, 2009
     
 
 
Infrastructure & Environment
  $ 831.6     $ (770.7 )   $     $ 2.6     $ 63.5  
Federal Services
    634.4       (600.4 )           1.9       35.9  
Energy & Construction
    1,073.3       (1,027.0 )           35.5       81.8  
Eliminations
    (18.7 )     18.7                    
Corporate
                (18.1 )           (18.1 )
Total
  $ 2,520.6     $ (2,379.4 )   $ (18.1 )   $ 40.0     $ 163.1  
                                         
Increase (decrease) for the three months ended
April 2, 2010 and April 3, 2009
     
 
 
Infrastructure & Environment
  $ (56.5 )   $ (46.1 )   $     $ (1.7 )   $ (12.1 )
Federal Services
    3.1       2.9             (0.4 )     (0.2 )
Energy & Construction
    (265.2 )     (255.0 )           (13.2 )     (23.4 )
Eliminations
    5.5       5.5                    
Corporate
                2.2             (2.2 )
Total
  $ (313.1 )   $ (292.7 )   $ 2.2     $ (15.3 )   $ (37.9 )
                                         
Percentage increase (decrease) for the three months
ended
April 2, 2010 and April 3, 2009
     
 
 
Infrastructure & Environment
    (6.8 %)     (6.0 %)           (65.4 %)     (19.1 %)
Federal Services
    0.5 %     0.5 %           (21.1 %)     (0.6 %)
Energy & Construction
    (24.7 %)     (24.8 %)           (37.2 %)     (28.6 %)
Eliminations
    (29.4 %)     (29.4 %)                  
Corporate
                12.2 %           12.2 %
Total
    (12.4 %)     (12.3 %)     12.2 %     (38.3 %)     (23.2 %)


Revenues
 
Our consolidated revenues for the three months ended April 2, 2010 were $2.2 billion, a decrease of $313.1 million or 12.4% compared with the three months ended April 3, 2009.  Revenues from our Infrastructure & Environment business for the three months ended April 2, 2010 were $775.1 million, a decrease of $56.5 million or 6.8% compared with the three months ended April 3, 2009.  Revenues from our Federal Services business for the three months ended April 2, 2010 were $637.5 million, an increase of $3.1 million or 0.5% compared with the three months ended April 3, 2009.  Revenues from our Energy & Construction business for the three months ended April 2, 2010 were $808.1 million, a decrease of $265.2 million or 24.7% compared with the three months ended April 3, 2009.
 
The revenues reported above are presented prior to elimination of inter-segment transactions.  Our analysis of these changes in revenues is set forth below.
 
Power
 
Consolidated revenues from our power market sector for the three months ended April 2, 2010 were $290.1 million, a decrease of $138.6 million or 32.3% compared with the three months ended April 3, 2009.  The decline in revenues in the power sector reflects the completion of several major emissions control projects that experienced high levels of activity in the comparable period in fiscal 2009.  Projects of this type, which involve the retrofit of coal-fired power plants with clean air technology to reduce sulfur dioxide, mercury and other emissions, are driven by the timing of regulatory mandates, such as the Clean Air Interstate Rule.  Many of our clients have completed projects that will enable them to meet the Rule’s 2010 deadline for emissions reductions, and we have experienced a delay in the start-up of new projects to meet the Rule’s 2015 deadline for additional emissions reductions.  In addition, as a result of the economic downturn, several power clients have deferred or cancelled large capital improvement projects.  The impact of these factors was partially offset by strong demand for the engineering and construction services to develop new gas-fired power plants, as well as for the advanced nuclear technology services we provide to increase the generating capacity and extend the service life of existing nuclear power plants.
 
The Infrastructure & Environment business’ revenues from our power market sector for the three months ended April 2, 2010 were $31.7 million, a decrease of $16.0 million or 33.5% compared with the three months ended April 3, 2009.  Power revenues declined in the Infrastructure & Environment business due to the completion of several major emissions control projects.  In the comparable period in fiscal 2009, these projects experienced higher levels of construction and procurement activity and generated higher revenues.  Additionally, as we are awarded new contracts to provide emissions control services, these assignments are typically being performed within our Energy & Construction business.  By contrast, revenues increased from the services we provide to upgrade transmission and distribution systems to improve reliability and support the delivery of renewable energy.
 
The Energy & Construction business’ revenues from our power market sector for the three months ended April 2, 2010 were $258.4 million, a decrease of $122.6 million or 32.2% compared with the three months ended April 3, 2009.  The decline in revenues was primarily due to the completion of several major projects involving the retrofit of coal-fired power plants with clean air technologies, which accounted for a decrease in revenues of $148.0 million, and a project to construct a uranium enrichment facility, which accounted for an additional decrease of $22.2 million.  These decreases were partially offset by a revenue increase of $42.9 million resulting from a newly consolidated joint venture that provides engineering, procurement, maintenance, and construction services for large nuclear component replacement projects.
 


Infrastructure
 
Consolidated revenues from our infrastructure market sector for the three months ended April 2, 2010 were $471.2 million, an increase of $23.6 million or 5.3% compared with the three months ended April 3, 2009.  The increase in infrastructure revenues was primarily due to increased activity on an ongoing dam construction project in Illinois and a new contract to construct a flood protection wall in Louisiana.  We also continued to benefit from strong demand for the program management, planning, design and engineering services we provide to expand rail/transit systems and to modernize and improve air transportation infrastructure.  Although the economic downturn and declining tax revenues have led to reductions in infrastructure spending by many state and local governments, an increasing portion of our infrastructure work is being funded by a variety of other sources, such as bonds, user fees, dedicated tax measures and the ARRA.
 
The Infrastructure & Environment business’ revenues from our infrastructure market sector for the three months ended April 2, 2010 were $357.2 million, a decrease of $12.8 million or 3.5% compared with the three months ended April 3, 2009.  The moderate decline in revenues was largely the result of spending reductions by state and local governments for key infrastructure programs.  At the same time, we continued to benefit from other sources of infrastructure funding, including bond sales, user fees, dedicated tax measures and the ARRA.  While revenues declined moderately from the services we provide to rehabilitate and expand surface transportation systems, schools, healthcare complexes and other public facilities, we generated increased revenues from airport, rail/transit and water supply, distribution and treatment projects.
 
The Energy & Construction business’ revenues from our infrastructure market sector for the three months ended April 2, 2010 were $114.0 million, an increase of $36.4 million or 46.9% compared with the three months ended April 3, 2009.  The increase was driven by high levels of activity on a new construction project to rebuild a flood protection wall in Louisiana, which increased revenues by $42.1 million, and an ongoing dam construction project on the Ohio River in Illinois, which increased revenues by $15.3 million.  This increase was partially offset by two events recorded in the comparable period in the previous year:  a $19.5 million favorable settlement of subcontractor claims for a highway construction project in California and a $7.0 million one-time award fee for a transit project in Washington, D.C.
 
Federal
 
Consolidated revenues from our federal market sector for the three months ended April 2, 2010 were $1.1 billion, an increase of $121.3 million or 12.8% compared with the three months ended April 3, 2009.  Our increase in revenues in the federal market sector reflects strong demand for the engineering, construction and technical services we provide to the DOD, DOE, NASA and other federal government agencies.  Revenues increased from the environmental and nuclear management services we provide to the DOE, primarily due to a rebid DOE contract involving the treatment and disposal of high-level liquid waste.  We also continued to benefit from strong demand for systems engineering and technical assistance services we provide to the DOD to modernize aging weapons systems and develop new systems, as well as from our operations and installation management services at military bases, test ranges, space flight centers and other government installations.  In addition, demand increased for the engineering, construction and environmental services we provide at military installations in the U.S. and internationally in support of DOD initiatives to realign military bases and redeploy troops to meet evolving security needs.
 
The Infrastructure & Environment business’ revenues from our federal market sector for the three months ended April 2, 2010 were $175.0 million, an increase of $11.0 million or 6.7% compared with the three months ended April 3, 2009.  This increase was largely driven by strong demand for the engineering, construction and environmental services we provide to the DOD at military installations in the U.S. and internationally.  Many of these assignments support the DOD’s long-term Military Transformation Initiative to realign military bases and redeploy troops to meet the evolving security needs of the post-Cold War era.  Our work typically involves the design and construction of aircraft hangars, barracks, military hospitals, and other government buildings, as well as the environmental remediation and restoration of military installations.
 


The Federal Services business’ revenues from our federal market sector for the three months ended April 2, 2010 were $636.7 million, an increase of $3.1 million or 0.5% compared with the three months ended April 3, 2009.  Revenues increased from the specialized systems engineering and technical assistance services we provide to the DOD for the development, testing and evaluation of new weapons systems and the modernization of aging weapons systems.  We also benefited from steady demand for operations and installation management services to support the operations of complex government and military installations, such as military bases, test ranges, space flight centers and other government installations.  By contrast, revenues declined moderately from the services we provide in support of chemical demilitarization programs involving the elimination of chemical and biological weapons of mass destruction.
 
The Energy & Construction business’ revenues from our federal market sector for the three months ended April 2, 2010 were $260.8 million, an increase of $107.2 million or 69.8% compared with the three months ended April 3, 2009.  The increase was primarily driven by a rebid DOE contract to provide nuclear management services for the treatment and disposal of high-level liquid waste, which resulted in an increase in revenues of $96.0 million compared to the same period in fiscal year 2009 based on a change in the contract structure.  The rebid contract is accounted for as an at-risk contract; whereas, the previous contract was an agency contract.  Revenues also increased by $13.9 million from a new contract to provide management and operations services to a federal energy technology laboratory.
 
Industrial and Commercial
 
Consolidated revenues from our industrial and commercial market sector for the three months ended April 2, 2010 were $373.7 million, a decrease of $319.4 million or 46.1% compared with the three months ended April 3, 2009.  The industrial and commercial market sector, which includes the work we perform for oil and gas, mining and manufacturing clients, continues to be the most exposed to the current economic downturn because many of these clients are dependent on oil and gas and commodity prices to support capital expenditure programs.  We continued to experience a significant decline in revenues, due largely to a decrease in activity on several major construction contracts and the delay or deferral of new, large-scale capital improvement projects.  In addition, demand decreased for the services we provide to develop and operate mines.  As a result of the decline in the prices of metals and mineral resources during the past fiscal year, many of our mining clients have curtailed mining activities and, in some cases, suspended existing mining operations.  By contrast, revenues have remained steady from the facilities management services we provide, as manufacturing clients continued to outsource non-core functions to manage their overhead costs.  We also benefited from stable demand for the environmental and engineering work we provide under long-term Master Service Agreements (“MSAs”) with multinational corporations.
 
The Infrastructure & Environment business’ revenues from our industrial and commercial market sector for the three months ended April 2, 2010 were $202.9 million, a decrease of $31.3 million or 13.4% compared with the three months ended April 3, 2009.  Revenues declined due to a decrease in demand for the engineering and construction-related services we provide to clients in the oil and gas and manufacturing industries related to major capital improvement projects.  By contrast, we continued to benefit from stable demand for the environmental and engineering work we provide under MSAs with multinational corporations.  Because this work is typically driven by regulatory compliance requirements and supports existing facility operations, it tends to be less susceptible to economic downturns and reductions in capital spending.  Due to the economic downturn and its effect on the businesses of our commercial clients, such as real estate developers, transportation/freight carriers, telecommunications providers and financial services providers, we also experienced decreased demand for the services we provide to these clients.
 


The Energy & Construction business’ revenues from our industrial and commercial market sector for the three months ended April 2, 2010 were $170.8 million, a decrease of $288.1 million or 62.8% compared with the three months ended April 3, 2009.  The decrease is primarily driven by the completion of major construction projects, including a $135.2 million decrease related to a cement manufacturing plant in Missouri and a $70.1 million decrease related to three oil and gas projects.  Due to the economic downturn and the decline in the prices of metals and mineral resources during 2009, which led many of our mining clients to curtail mining operations and, in some cases, close mines, revenues for the services we provide to develop and operate mines also declined by $50.3 million over the same period in the prior year.
 
Cost of Revenues
 
Our consolidated cost of revenues, which consists of labor, subcontractor costs, and other expenses related to projects and services provided to our clients, decreased by 12.3% for the three months ended April 2, 2010 compared with the three months ended April 3, 2009.  Because our revenues are primarily project-based, the factors that caused revenues to decline also drove a corresponding decrease in our cost of revenues.  Consolidated cost of revenues as a percent of revenues increased slightly from 94.4% for the first quarter of 2009 to 94.5% for the first quarter of 2010.
 
General and Administrative Expenses
 
Our consolidated general and administrative (“G&A”)expenses for the three months ended April 2, 2010 increased by 12.2% compared with the three months ended April 3, 2009.  The increase was primarily due to foreign currency losses related to intercompany balances resulting from the strengthening of the U.S. dollar.  The foreign currency losses were offset by foreign currency gains recorded in our Infrastructure & Environment business and our Energy & Construction business.  Consolidated G&A expenses as a percent of revenues was 0.9% for the three months ended April 2, 2010 compared to 0.7% for the three months ended April 3, 2009.
 
Equity in Income of Unconsolidated Joint Ventures
 
Our consolidated equity in income of unconsolidated joint ventures for the three months ended April 2, 2010 decreased by $15.3 million or 38.3% compared with the three months ended April 3, 2009.  The decrease for the three-month period comparisons was attributable primarily to the Energy & Construction business’ unconsolidated joint ventures as discussed below.
 
The Energy & Construction business’ equity in income of unconsolidated joint ventures for the three months ended April 2, 2010 decreased by $13.2 million or 37.2% compared with the three months ended April 3, 2009.  The decrease was due to:
 
·  
A $15.3 million decrease in equity in income resulting from the sale of our equity investment in MIBRAG on June 10, 2009; and
 
·  
A $9.7 million decrease during the first quarter of 2010, primarily caused by the consolidation of several joint ventures in the current period.
 
These decreases were offset by:
 
·  
A $9.5 million increase from the consolidation of a U.K. joint venture whose sole operations consist of an investment in another U.K. joint venture, which it did not consolidate during the three months ended April 2, 2010; and
 
·  
A $3.1 million increase from the consolidation of a second U.K. joint venture whose operations consist of an investment in another U.K. joint venture, which it consolidated during the three months ended April 3, 2009, but did not consolidate during the three months ended April 2, 2010.
 


Operating Income
 
Our consolidated operating income for the three months ended April 2, 2010 decreased by $37.9 million or 23.2% compared with the three months ended April 3, 2009.  As a percentage of revenues, operating income was 5.7% for the three months ended April 2, 2010 compared to 6.5% for the three months ended April 3, 2009.  The decrease in operating income reflected primarily the decreases in revenues and in equity in income of unconsolidated joint ventures described above, as well as an increase in insurance expenses.  In addition, the decline was also due to the completion of various projects that generated operating income in the first quarter of 2009.  These decreases were partially offset by a $31.9 million increase resulting from the newly consolidated joint ventures during the first quarter of fiscal year 2010.  These items are discussed further below.
 
The Infrastructure & Environment business’ operating income for the three months ended April 2, 2010 decreased by $12.1 million or 19.1% compared with the three months ended April 3, 2009.  The decrease in operating income was caused primarily by the decrease in revenues previously described, as well as an increase in insurance expenses of $5.2 million.  The decline in earnings was offset in part by reductions in the use of subcontractors and purchases of project-related materials, which provide lower profit margins than activities performed directly by our employees.  Overhead costs as a percentage of revenues increased slightly from 31.9% for the three months ended April 3, 2009 to 32.9% for the three months ended April 2, 2010.  Operating income as a percentage of revenues was 6.6% for the three months ended April 2, 2010 compared to 7.6% for the three months ended April 3, 2009.
 
The Federal Service business’ operating income for the three months ended April 2, 2010 decreased by $0.2 million or 0.6% compared with the three months ended April 3, 2009.  The decline in operating income was primarily due to higher investment in business development costs.  Operating income as a percentage of revenues was 5.6% for the three months ended April 2, 2010 compared to 5.7% for the three months ended April 3, 2009.
 
The Energy & Construction business’ operating income for the three months ended April 2, 2010 decreased $23.4 million or 28.6% compared with the three months ended April 3, 2009.  The decline in operating income was primarily driven by the decrease in revenues previously described and as a result of several events that occurred in the comparable period of fiscal year 2009 that did not recur in 2010.  The decrease was partially offset by higher operating income resulting from the newly consolidated joint ventures during the first quarter of fiscal year 2010.  The non-recurring events in the three months ended April 3, 2009 included the recognition of a $15.2 million change order recovery on a highway project, a $9.0 million contract termination fee related to a contract mining project, and a $7.0 million project development success fee related to a transit project.  In addition, operating income in the prior period included $15.3 million in earnings from MIBRAG, which was sold on June 10, 2009.
 
These declines in operating income were partially offset by $16.1 million in higher earnings resulting from the newly consolidated joint ventures during the first quarter of fiscal year 2010 and the achievement and recognition of a $10.0 million schedule incentive on a clean air power project in Maryland.  In addition, overhead costs decreased by $4.7 million from the comparable period of fiscal year 2009, which were driven by lower business development costs resulting from the timing of major proposals and cost-control measures taken in response to the ongoing economic downturn.  Operating income as a percentage of revenues was 7.2% for the three months ended April 2, 2010 compared to 7.6% for the three months ended April 3, 2009.
 
Interest Expense
 
Our consolidated interest expense for the three months ended April 2, 2010 decreased by $5.4 million or 36.7% compared with the three months ended April 3, 2009.  These decreases were due to lower debt balances as a result of debt payments on our Senior Secured Credit Facility (“2007 Credit Facility”), in addition to lower LIBOR interest rates and lower interest rate margins in 2010.
 


Other Expenses
 
Our consolidated other expenses for the three months ended April 3, 2009 consisted of $6.2 million of unrealized loss on a foreign currency forward contract we entered into during the first quarter of fiscal year 2009 and $1.4 million of expenses associated with the sale of our equity investment in MIBRAG, which closed in the second quarter of 2009.  We have not incurred expenses of this kind in the first quarter of 2010.
 
Income Tax Expense
 
Our effective income tax rates for the three months ended April 2, 2010 and April 3, 2009 were 1.9% and 41.0%, respectively.  The reduction in the rate was primarily due to our determination made during the first quarter of 2010 that earnings of our foreign subsidiaries will be indefinitely reinvested offshore, which resulted in the reversal of the net U.S. deferred tax liability on the undistributed earnings of all foreign subsidiaries.  On February 16, 2010, we entered into a consent with our lenders related to our 2007 Credit Facility that permits us to utilize the funds received in June 2009 from the sale of our equity investment in MIBRAG for general operating purposes.  This consent allows these funds to be indefinitely reinvested offshore as part of our strategy to expand our international business.  During the three months ended April 2, 2010, we further developed this strategy from the indefinite reinvestment of the earnings of a single foreign subsidiary to the indefinite reinvestment of the earnings of all of our foreign subsidiaries.
 
   
April 2, 2010
   
April 3, 2009
 
   
Amount
   
Tax Rate
   
Amount
   
Tax Rate
 
U.S. statutory rate applied to income before taxes
  $ 40,547       35.0 %   $ 49,292       35.0 %
State taxes, net of federal benefit
    5,298       4.6       6,508       4.6  
Change in indefinite reinvestment assertion
    (61,097 )     (52.7 )            
Adjustments to valuation allowances
    8,811       7.6              
Adjustments related to changing foreign tax credits to deductions
    13,616       11.8              
Foreign income taxed at rates other than 35%
    (4,686 )     (4.1 )     89        
Other adjustments
    (307 )     (0.3 )     1,746       1.4  
Total income tax expense
  $ 2,182       1.9 %   $ 57,635       41.0 %
 
LIQUIDITY AND CAPITAL RESOURCES
 
   
Three Months Ended
 
(In millions)
 
April 2,
2010
   
April 3,
2009
 
Cash flows from operating activities
  $ (66.0 )   $ 221.3  
Cash flows from investing activities
    41.6       (14.9 )
Cash flows from financing activities
    (57.8 )     (43.0 )
 
Overview
 
During the three months ended April 2, 2010, our primary sources of liquidity were collections of accounts receivable from our clients, dividends from our unconsolidated joint ventures and the maturity of our short-term investment.  Our primary uses of cash were to fund our working capital, capital expenditures, income tax payments and distributions to the noncontrolling interests in our consolidated joint ventures; to invest in our unconsolidated joint ventures; to service our debt; and to purchase treasury stock.
 
Our cash flows from operations are primarily impacted by fluctuations in working capital, which is affected by numerous factors, including billing and payment terms of our contracts, stage of completion of contracts performed by us, timing of our payroll payments relative to our fiscal quarter ends, or unforeseen events or issues that may have an impact on our working capital.
 


Liquidity
 
Cash and cash equivalents include all highly liquid investments with maturities of 90 days or less at the date of purchase, including interest-bearing bank deposits and money market funds.  Restricted cash is included in other current assets because it was not material.  As of April 2, 2010 and January 1, 2010, cash and cash equivalents included $138.0 million and $112.4 million, respectively, of cash held by our consolidated joint ventures.
 
Accounts receivable and costs and accrued earnings in excess of billings on contracts represent our primary source of operational cash inflows.  Costs and accrued earnings in excess of billings on contracts represent amounts that will be billed to clients as soon as invoice support can be assembled, reviewed and provided to our clients, or when specific contractual billing milestones are achieved.  In some cases, unbilled amounts may not be billable for periods generally extending from two to six months and, rarely, beyond a year.  As of April 2, 2010 and January 1, 2010, significant unapproved change orders and claims, which are included in costs and accrued earnings in excess of billings on contracts, collectively represented approximately 4% of our gross accounts receivable and accrued earnings in excess of billings on contracts, for both periods.
 
All accounts receivable and costs and accrued earnings in excess of billings on contracts are evaluated on a regular basis to assess the risk of collectability and allowances are provided as deemed appropriate.  Based on the nature of our customer base, including U.S. federal, state and local governments and large reputable companies, and contracts, we have not historically experienced significant write-offs related to receivables and costs and accrued earnings in excess of billings.  The size of our allowance for uncollectible receivables as a percentage of the combined totals of our accounts receivable and accrued earnings in excess of billings on contracts is indicative of our history of successfully billing costs and accrued earnings in excess of billings on contracts and collecting the billed amounts from our clients.
 
As of April 2, 2010 and January 1, 2010, our receivable allowances represented 2.10% and 2.45%, respectively, of the combined total accounts receivable and costs and accrued earnings in excess of billings on contracts.  We believe that our allowance for doubtful accounts receivable as of April 2, 2010 is adequate.  We have placed significant emphasis on collection efforts and continually monitor our receivable allowance.  However, future economic conditions may adversely affect the ability of some of our clients to make payments or the timeliness of their payments; consequently, it may also affect our ability to consistently collect cash from our clients and meet our operating needs.  The other significant factors that typically affect our realization of our accounts receivable include the billing and payment terms of our contracts, as well as the stage of completion of our performance under the contracts.  Changes in contract terms or the position within the collection cycle of contracts, for which our joint ventures, partnerships and partially-owned limited liability companies have received advance payments, can affect our operating cash flows.  In addition, substantial advance payments or billings in excess of costs also have an impact on our liquidity.  Billings in excess of costs as of April 2, 2010 and January 1, 2010 were $212.6 million and $235.3 million, respectively.
 
We use Days Sales Outstanding (“DSO”) to monitor the average time, in days, that it takes us to convert our accounts receivable into cash.  We calculate DSO by dividing net accounts receivable less billings in excess of costs and accrued earnings on contracts as of the end of the quarter into the amount of revenues recognized during the quarter, and multiplying the result of that calculation by the number of days in that quarter.  Our DSO increased from 72 days as of January 1, 2010 to 81 days as of April 2, 2010.  The increase in DSOs was a result of several factors, including:
 
·  
The mobilization and ramp-up of a new contract to provide construction services for the rebuilding of a flood protection wall in Louisiana;
 
·  
The inclusion of $115.9 million of net accounts receivable less billings in excess of costs and accrued earnings on contracts as of January 1, 2010 into the DSO calculation from newly consolidated joint ventures;
 
·  
The continued suspension of the direct billing privileges of our Federal Services business since last year.  We anticipate that the U.S. Defense Contract Audit Agency will reinstate the direct billing privileges of our Federal Services business, although no assurance can be given as to the timing of any potential reinstatement;
 


·  
The delay in collection of a large federal contract pending resolution of contract billing terms; and
 
·  
A general slowdown in collections and lengthening of payment terms.
 
We believe that we have sufficient resources to fund our operating and capital expenditure requirements, pay income taxes, as well as to service our debt, for at least the next twelve months.  In the ordinary course of our business, we may experience various loss contingencies including, but not limited to, the pending legal proceedings identified in Note 14, “Commitments and Contingencies,” to our Condensed Consolidated Financial Statements included under Part 1 – Item 1 of this report, which may adversely affect our liquidity and capital resources.
 
Operating Activities
 
The decrease in cash flows from operating activities for the three months ended April 2, 2010, compared to the three months ended April 3, 2009, was primarily due to a decrease in our operating income, and fluctuations in receivables and payables as a result of the timing of payroll payments, payments from clients on accounts receivable, and payments to vendors, subcontractors, and joint ventures.  In addition, we made income tax payments of $2.8 million during the first quarter of fiscal year 2010 compared to receipt of a net tax refund of $20.1 million during the first quarter of fiscal year 2009.  Furthermore, the decrease was partially offset by a decrease in interest payments.
 
Investing Activities
 
With the exception of the construction and mining activities within our Energy & Construction business, we are not capital intensive.  Our mining activities require the use of heavy equipment, which are either owned or leased.  Our other capital expenditures are primarily for various information systems to support our professional and technical services and administrative needs.
 
Capital expenditures, excluding purchases financed through capital leases and equipment notes, during the three months ended April 2, 2010 and April 3, 2009 were $7.4 million and $9.3 million, respectively.
 
In addition, we disbursed $2.5 million and $6.5 million in cash related to investments in and advances to unconsolidated joint ventures for the three months ended April 2, 2010 and April 3, 2009, respectively.  Furthermore, a short-term investment of $30.0 million matured during the first quarter of fiscal year 2010.
 
Our cash balance increased by $20.7 million at the beginning of our first quarter of fiscal year 2010 as a result of newly consolidated joint ventures.
 
For the remainder of fiscal year 2010, we expect to incur approximately $62 million in capital expenditures, a portion of which will be financed through capital leases or equipment notes.
 
Financing Activities
 
The decrease in net cash flows from financing activities for the three months ended April 2, 2010, compared to the three months ended April 3, 2009, was primarily due to an increase in repurchases of our common stock, partially offset by changes in net distributions to noncontrolling interests and changes in overdrafts.
 
Cash flows used for financing activities of $57.8 million during the three months ended April 2, 2010 consisted of the following significant activities:
 
·  
Purchases of treasury stock of $48.4 million;
 
·  
Net distributions to noncontrolling interests of $4.1 million; and
 
·  
Decreases in overdrafts of $4.6 million.
 
Cash flows used for financing activities of $43.0 million during the three months ended April 3, 2009 consisted of the following significant activities:
 
·  
Purchases of treasury stock of $24.0 million;
 
·  
Net distributions to noncontrolling interests of $19.1 million; and
 
·  
Increases in overdrafts of $3.2 million.
 
Contractual Obligations and Commitments
 
The following table contains information about our contractual obligations and commercial commitments followed by narrative descriptions as of April 2, 2010.
 
   
Payments and Commitments Due by Period
 
Contractual Obligations
(Debt payments include principal only)
(In millions)
 
Total
   
Less Than 1 Year
   
1-3 Years
   
4-5 Years
   
After
5 Years
   
Other
 
As of April 2, 2010:
                                   
2007 Credit Facility (1,2) 
  $ 775.0     $     $ 703.4     $ 71.6     $     $  
Capital lease obligations (1) 
    15.1       6.7       6.5       1.9              
Notes payable, foreign credit lines and other indebtedness (1)
    23.1       9.6       11.4       2.1              
Total debt
    813.2       16.3       721.3       75.6              
Operating lease obligations (3) 
    494.6       145.1       196.2       107.0       46.3        
Pension and other retirement plans funding requirements (4)
    270.0       33.0       59.8       47.2       130.0        
Interest (5) 
    69.3       23.3       44.3       1.7              
Purchase obligations (6) 
    6.2       1.3       0.6             4.3        
Asset retirement obligations (7) 
    3.8       0.7       1.2       1.7       0.2        
Other contractual obligations (8) 
    33.9       7.9       5.0                   21.0  
Total contractual obligations
  $ 1,691.0     $ 227.6     $ 1,028.4     $ 233.2     $ 180.8     $ 21.0  

(1)
Amounts shown exclude unamortized debt issuance costs of $8.9 million for the 2007 Credit Facility.  For capital lease obligations, amounts shown exclude interest of $1.2 million.
 
 
(2)
On February 16, 2010, we entered into a consent to our 2007 Credit Facility, which allows us to utilize the funds from the sale of our equity investment in MIBRAG for general operating purposes.  Accordingly, we are not required to remit $100.0 million as repayment on our 2007 Credit Facility in fiscal year 2010.  Our next scheduled payment is expected to be due in December 2011.
 
 
(3)
Operating leases are predominantly real estate leases.
 
 
(4)
Amounts consist of estimated pension and other retirement plan funding requirements for various pension, post-retirement, and other retirement plans.
 
 
(5)
Interest for the next five years, which excludes non-cash interest, is determined based on the current outstanding balance of our debt and payment schedule at the estimated interest rate including the effect of the interest rate swaps.
 
 
(6)
Purchase obligations consist primarily of software maintenance contracts.
 
 
(7)
Asset retirement obligations represent the estimated costs of removing and restoring our leased properties to the original condition pursuant to our real estate lease agreements.
 
 
(8)
Other contractual obligations include net liabilities for anticipated settlements and interest under our tax liabilities, accrued severance for our CEO pursuant to his employment agreement, and our contractual obligations to joint ventures.  Generally, it is not practicable to forecast or estimate the payment dates for the above-mentioned tax liabilities.  Therefore, we included the estimated liabilities under the “Other” column above.
 
 


Off-balance Sheet Arrangements
 
In the ordinary course of business, we may use off-balance sheet arrangements if we believe that such an arrangement would be an efficient way to lower our cost of capital or help us manage the overall risks of our business operations.  We do not believe that such arrangements have had a material adverse effect on our financial position or our results of operations.
 
The following is a list of our off-balance sheet arrangements:
 
·  
Letters of credit primarily to support project performance, insurance programs, bonding arrangements and real estate leases.  As of April 2, 2010, we had $212.7 million in standby letters of credit under our 2007 Credit Facility.  We are required to reimburse the issuers of letters of credit for any payments they make under the outstanding letters of credit.  Our 2007 Credit Facility covers the issuance of our standby letters of credit and is critical for our normal operations.  If we default on the 2007 Credit Facility, our inability to issue or renew standby letters of credit would impair our ability to maintain normal operations.
 
·  
We have guaranteed a letter of credit issued on behalf of one of our consolidated joint ventures.  The total amount of the letter of credit was $7.2 million as of April 2, 2010.
 
·  
We have agreed to indemnify one of our joint venture partners up to $25.0 million for any potential losses and damages, and liabilities associated with lawsuits in relation to general and administrative services we provide to the joint venture.  Currently, we have not been advised of any indemnified claims under this guarantee.
 
·  
As of April 2, 2010, the amount of a guarantee used to collateralize the credit facility of one of our U.K. operating subsidiaries and bank guarantee lines of some of our European subsidiaries was $8.0 million.
 
·  
From time to time, we provide guarantees related to our services or work.  If our services under a guaranteed project are later determined to have resulted in a material defect or other material deficiency, then we may be responsible for monetary damages or other legal remedies.  When sufficient information about claims on guaranteed projects is available and monetary damages or other costs or losses are determined to be probable, we recognize such guarantee losses.
 
·  
In the ordinary course of business, we enter into various agreements providing performance assurances and guarantees to clients on behalf of certain unconsolidated subsidiaries, joint ventures, and other jointly executed contracts.  We enter into these agreements primarily to support the project execution commitments of these entities.  The potential payment amount of an outstanding performance guarantee is typically the remaining cost of work to be performed by or on behalf of third parties under engineering and construction contracts.  However, we are not able to estimate other amounts that may be required to be paid in excess of estimated costs to complete contracts and, accordingly, the total potential payment amount under our outstanding performance guarantees cannot be estimated.  For cost-plus contracts, amounts that may become payable pursuant to guarantee provisions are normally recoverable from the client for work performed under the contract.  For lump sum or fixed-price contracts, this amount is the cost to complete the contracted work less amounts remaining to be billed to the client under the contract.  Remaining billable amounts could be greater or less than the cost to complete.  In those cases where costs exceed the remaining amounts payable under the contract, we may have recourse to third parties, such as owners, co-venturers, subcontractors or vendors, for claims.
 
·  
In the ordinary course of business, our clients may request that we obtain surety bonds in connection with contract performance obligations that are not required to be recorded in our condensed consolidated balance sheets.  We are obligated to reimburse the issuer of our surety bonds for any payments made hereunder.  Each of our commitments under performance bonds generally ends concurrently with the expiration of our related contractual obligation.
 


2007 Credit Facility
 
As of both April 2, 2010 and January 1, 2010, the outstanding balance of term loan A was $607.6 million at interest rates of 1.29% and 1.25%, respectively.  As of both April 2, 2010 and January 2, 2009, the outstanding balance of term loan B was $167.4 million at interest rates of 2.54% and 2.50%, respectively.
 
Under the terms of our 2007 Credit Facility, we are generally required to remit as debt payments any proceeds we receive from the sale of assets and the issuance of debt.  On February 16, 2010, we entered into a consent to our 2007 Credit Facility, which allows us to use the funds from the sale of our equity investment in MIBRAG for general operating purposes.  As a result of this consent, we are no longer required to remit a payment relating to this asset sale in the first quarter of 2010 and our next scheduled payment is expected to be due in December 2011.
 
Under our 2007 Credit Facility, we are subject to two financial covenants: 1) a maximum consolidated leverage ratio, which is calculated by dividing consolidated total debt by consolidated EBITDA, as defined below, and 2) a minimum interest coverage ratio, which is calculated by dividing consolidated cash interest expense into consolidated EBITDA.  Both calculations are based on the financial data of the most recent four fiscal quarters.
 
For purposes of our 2007 Credit Facility, consolidated EBITDA is defined as consolidated net income attributable to URS plus interest, depreciation and amortization expense, amounts set aside for taxes, other non-cash items (including goodwill impairments) and other pro forma adjustments related to permitted acquisitions and the Washington Group International, Inc. acquisition in 2007.
 
As of April 2, 2010, our consolidated leverage ratio was 1.3, which did not exceed the maximum consolidated leverage ratio of 2.375, and our consolidated interest coverage ratio was 17.8, which exceeded the minimum consolidated interest coverage ratio of 5.0.  During the first quarter of 2010, Moody’s Investor Services upgraded our credit rating to Ba1.  On April 16, 2010, Standard and Poor’s upgraded our credit rating to BB+.  As a result of our upgraded credit ratings, some of our non-financial covenants are no longer applicable or became less restrictive; such as the ability to acquire other companies.  We were in compliance with the covenants of our 2007 Credit Facility as of April 2, 2010.
 
13BRevolving Line of Credit
 
We did not have an outstanding debt balance on our revolving line of credit as of April 2, 2010 and January 1, 2010.  As of April 2, 2010, we have issued $212.7 million of letters of credit, leaving $487.3 million available on our revolving credit facility.  If we elected to borrow the remaining amounts available under our revolving line of credit as of April 2, 2010, we would remain in compliance with the covenants of our 2007 Credit Facility.
 
14BOther Indebtedness
 
Notes payable, foreign credit lines and other indebtedness.  As of April 2, 2010 and January 1, 2010, we had outstanding amounts of $23.1 million and $24.6 million, respectively, in notes payable and foreign lines of credit.  Notes payable primarily include notes used to finance the purchase of office equipment, computer equipment and furniture.  The weighted-average interest rates of the notes payable were approximately 5.5% and 5.6% as of April 2, 2010 and January 1, 2010, respectively.
 
We maintain foreign lines of credit, which are collateralized by the assets of our foreign subsidiaries and, in some cases, parent guarantees.  As of April 2, 2010 and January 1, 2010, we had lines of credit available under these facilities of $15.8 million, with no amounts outstanding.
 
Capital Leases.  As of April 2, 2010 and January 1, 2010, we had obligations under our capital leases of approximately $15.1 million and $16.5 million, respectively, consisting primarily of leases for office equipment, computer equipment and furniture.
 


Operating Leases.  As of April 2, 2010 and January 1, 2010, we had obligations under our operating leases of approximately $494.6 million and $489.8 million, respectively, consisting primarily of real estate leases.
 
Other Activities
 
Interest Rate Swap.  Our 2007 Credit Facility is a floating-rate facility.  To hedge against changes in floating interest rates, we have one floating-for-fixed interest rate swap with a notional amount of $200.0 million, maturing on December 31, 2010.  As of April 2, 2010 and January 1, 2010, the fair value of our interest rate swap liability was $5.6 million and $7.1 million, respectively.  The swap liability was recorded in “Other current liabilities” on our Condensed Consolidated Balance Sheets.  The adjustments to fair value of the swap liability were recorded in “Accumulated other comprehensive loss.”  We have recorded no gain or loss on our Condensed Consolidated Statements of Operations as our interest rate swap is an effective hedge.
 
CRITICAL ACCOUNTING POLICIES AND ESTIMATES
 
The preparation of consolidated financial statements in conformity with generally accepted accounting principles requires us to make estimates and assumptions in the application of certain accounting policies that affect amounts reported in our consolidated financial statements and related footnotes included in Item 1 of this report.  In preparing these financial statements, we have made our best estimates and judgments of certain amounts, after considering materiality.  Application of these accounting policies, however, involves the exercise of judgment and the use of assumptions as to future uncertainties.  Consequently, actual results could differ from our estimates, and these differences could be material.
 
The accounting policies that we believe are most critical to an investor’s understanding of our financial results and condition and that require complex judgments by management are included in our Annual Report on Form 10-K for the year ended January 1, 2010.  There were no material changes to these critical accounting policies during the three months ended April 2, 2010.  However, we adopted two new accounting standards relating to transfers of financial assets and consolidation of VIEs.  See the discussion on the adoption of the new accounting standards below.  We have also expanded our discussion of VIEs and goodwill below.
 
Consolidation of Variable Interest Entities
 
We participate in joint ventures, which include partnerships and partially-owned limited liability companies to bid, negotiate and complete specific projects.  We are required to consolidate these joint ventures if we hold the majority voting interest or if we meet the criteria under the variable interest model as described below.
 
A VIE is an entity with one or more of the following characteristics (a) the total equity investment at risk is not sufficient to permit the entity to finance its activities without additional financial support; (b) as a group, the holders of the equity investment at risk lack the ability to make certain decisions, the obligation to absorb expected losses or the right to receive expected residual returns; or (c) the equity investors have voting rights that are not proportional to their economic interests.
 
Our VIEs may be funded through contributions, loans and/or advances from the joint venture partners or by advances and/or letters of credit provided by our clients.  Our VIEs may be directly governed, managed, operated and administered by the joint venture partners.  Others have no employees and, although these entities own and hold the contracts with the clients, the services required by the contracts are typically performed by the joint venture partners or by other subcontractors.
 
If we are determined to be the primary beneficiary of the VIE, we are required to consolidate it.  We are considered to be the primary beneficiary if we have the power to direct the activities that most significantly impact the VIE’s economic performance and the obligation to absorb losses or the right to receive benefits of the VIE that could potentially be significant to the VIE.  In determining whether we are the primary beneficiary, our significant assumptions and judgments include the following:
 
·  
Identifying the significant activities and the parties that would perform them;
 

·  
Reviewing the governing board composition and participation ratio;
 
·  
Determining the equity, profit and loss ratio;
 
·  
Determining the management-sharing ratio;
 
·  
Reviewing employment terms, including which joint venture partner provides the project manager; and
 
·  
Reviewing the funding and operating agreements.
 
Examples of our significant activities include the following:
 
·  
Engineering services;
 
·  
Procurement services;
 
·  
Construction;
 
·  
Construction management; and
 
·  
Operations and maintenance services.
 
Based on the above, if we determine that the power to direct the significant activities is shared by two or more joint venture parties, then there is no primary beneficiary and no party consolidates the VIE.  In making the shared-power determination, we analyze the key contractual terms; governance; related party and de facto agency as they are defined in the accounting standard; and other arrangements to determine if the shared power exists.
 
As required by the accounting standard, we perform a quarterly reassessment of our status as primary beneficiary.  This evaluation may result in a newly consolidated joint venture or in deconsolidating a previously consolidated joint venture.  See Note 5, “Joint Ventures,” for further information on our VIEs.
 
 
Goodwill
 
Goodwill may be impaired if the estimated fair value of one or more of our reporting units’ goodwill is less than the carrying value of the unit’s goodwill.  Because we have grown through acquisitions, goodwill and other intangible assets represent a substantial portion of our total assets.  Goodwill and other net intangible assets were $3.6 billion as of April 2, 2010.  We perform an analysis on our goodwill balances to test for impairment on an annual basis and whenever events occur that indicate impairment could exist.  There are several instances that may cause us to further test our goodwill for impairment between the annual testing periods including:  (i) continued deterioration of market and economic conditions that may adversely impact our ability to meet our projected results; (ii) declines in our stock price caused by continued volatility in the financial markets that may result in increases in our weighted-average cost of capital or other inputs to our goodwill assessment; (iii) the occurrence of events that may reduce the fair value of a reporting unit below its carrying amount, such as the sale of a significant portion of one or more of our reporting units.  
 
For the three months ended April 2, 2010, no triggering events occurred that would require us to perform an interim impairment review of our goodwill.

 


ADOPTED AND OTHER RECENTLY ISSUED ACCOUNTING STANDARDS
 
A new accounting standard on transfers of financial assets became effective for us at the beginning of our 2010 fiscal year.  This standard eliminates the concept of a qualifying special-purpose entity, limits the circumstances under which a financial asset is derecognized and requires additional disclosures concerning a transferor's continuing involvement with transferred financial assets.  The adoption of this standard did not have a material impact on our condensed consolidated financial statements.
 
A new accounting standard on consolidation of variable interest entities (“VIEs”) became effective for us at the beginning of our 2010 fiscal year.  This standard amends the accounting and disclosure requirements for the consolidation of a VIE.  It requires additional disclosures about the significant judgments and assumptions used in determining whether to consolidate a VIE, the restrictions on a consolidated VIE’s assets and on the settlement of a VIE’s liabilities, the risk associated with involvement in a VIE, and the financial impact to a company due to its involvement with a VIE.  As the standard requires ongoing quarterly evaluation of the application of the new requirements, changes in circumstances could result in the identification of additional VIEs to be consolidated or existing VIEs to be deconsolidated in any reporting period.  We adopted this standard prospectively and based on the carrying values of the entities at the date of adoption.  The adoption of this standard did not have a material impact on our condensed consolidated financial statements.  For additional disclosures, see Note 5, “Joint Ventures,” to our “Condensed Consolidated Financial Statements,” included under Part 1 – Item 1 of this report.
 
An accounting standard update related to recurring and nonrecurring fair value measurements has been issued.  This update requires new disclosures on significant transfers of assets and liabilities between Level 1 and Level 2 of the fair value hierarchy (including the reasons for these transfers) and the reasons for any transfers in or out of Level 3.  It also requires a reconciliation of recurring Level 3 measurements including purchases, sales and issuances and settlements on a gross basis.  The accounting update clarifies certain existing disclosure requirements and provides fair value measurement disclosures for each class of assets and liabilities as opposed to each major category of assets and liabilities.  It also clarifies that entities are required to disclose information about both the valuation techniques and inputs used in estimating Level 2 and Level 3 fair value measurements.  Except for the disclosures on the reconciliation of recurring Level 3 measurements, the other new disclosures and clarifications of existing disclosures were effective for us beginning with the first quarter of our 2010 fiscal year.  The adoption of this standard did not have a material impact on our condensed consolidated financial statements.  See Note 8, “Fair Values of Debt Instruments, Short-Term Investments and Derivative Instruments” for our fair value measurement disclosure.  The information about the activity in Level 3 fair value measurements on a gross basis will be effective for us beginning with the first quarter of our 2011 fiscal year.  We are currently in the process of evaluating the impact on our consolidated financial statements from the adoption of this portion of the standard.
 
 
Interest Rate Risk
 
We are exposed to changes in interest rates as a result of our borrowings under our 2007 Credit Facility.  We have one floating-for-fixed interest rate swap with a notional amount of $200.0 million to hedge against changes in floating interest rates.  The notional amount of the swap is less than the outstanding debt and, as such, we are exposed to increasing or decreasing market interest rates on the unhedged portion.  Based on the expected outstanding indebtedness of approximately $775 million under our 2007 Credit Facility, if market rates used to calculate interest expense were to average 1% higher in the next twelve months, our net-of-tax interest expense would increase approximately $3.4 million.  As market rates are at historically low levels, the index rate used to calculate our interest expense cannot drop by more than 0.29%, which would lower our net-of-tax interest expense by approximately $1.0 million.  This analysis is computed taking into account the current outstanding balances of our 2007 Credit Facility, assumed interest rates, current debt payment schedule and the existing swap.  The result of this analysis would change if the underlying assumptions were modified.
 


Foreign Currency Risk
 
The majority of our transactions are in U.S. dollars; however, our foreign subsidiaries conduct businesses in various foreign currencies.  Therefore, we are subject to currency exposures and volatility because of currency fluctuations.  We attempt to minimize our exposure to foreign currency fluctuations by matching our revenues and expenses in the same currency for our operating contracts.  We had foreign currency translation gains, net of tax, of $1.1 million and foreign currency translation losses, net of tax, of $4.7 million for the three months ended April 2, 2010 and April 3, 2009, respectively.
 
ITEM 4.  CONTROLS AND PROCEDURES
 
Attached as exhibits to this Form 10-Q are certifications of our Chief Executive Officer (“CEO”) and Chief Financial Officer (“CFO”), which are required in accordance with Rule 13a-14 of the Securities Exchange Act of 1934, as amended (the “Exchange Act”).  This “Controls and Procedures” section includes information concerning the controls and controls evaluation referred to in the certifications and should be read in conjunction with the certifications for a more complete understanding.
 
Evaluation of Disclosure Controls and Procedures
 
Based on our management’s evaluation, with the participation of our CEO and CFO, of our “disclosure controls and procedures” (as defined in Rules 13a-15(e) and 15d-15(e) under the Exchange Act), our CEO and CFO have concluded that our disclosure controls and procedures were effective at a reasonable assurance level as of the end of the period covered by this report, to provide reasonable assurance that the information required to be disclosed by us in the reports that we filed or submitted to the Securities and Exchange Commission (“SEC”) under the Exchange Act were (1) recorded, processed, summarized and reported within the time periods specified in the SEC’s rules and forms and (2) accumulated and communicated to our management, including our principal executive and principal financial officers, to allow timely decisions regarding required disclosures.
 
Changes in Internal Control over Financial Reporting
 
During the quarter ended April 2, 2010, there were no changes in our internal control over financial reporting that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.
 
Inherent Limitations on Effectiveness of Controls
 
The company’s management, including the CEO and CFO, has designed our disclosure controls and procedures and our internal control over financial reporting to provide reasonable assurances that the controls’ objectives will be met.  However, management does not expect that disclosure controls and procedures or our internal control over financial reporting will prevent or detect all error and all fraud.  A control system, no matter how well designed and operated, can provide only reasonable, not absolute, assurance that the control system’s objectives will be met.  The design of a control system must reflect the fact that there are resource constraints, and the benefits of controls must be considered relative to their costs.  Further, because of the inherent limitations in all control systems, no evaluation of controls can provide absolute assurance that misstatements due to error or fraud will not occur or that all control issues and instances of fraud, if any, within the company have been detected.  These inherent limitations include the realities that judgments in decision-making can be faulty and that breakdowns can occur because of simple error or mistake.  Controls can also be circumvented by the individual acts of some persons, by collusion of two or more people, or by management override of the controls.  The design of any system of controls is based in part on certain assumptions about the likelihood of future events, and there can be no assurance that any system’s design will succeed in achieving its stated goals under all potential future conditions.  Projections of any evaluation of a system’s control effectiveness into future periods are subject to risks.  Over time, controls may become inadequate because of changes in conditions or deterioration in the degree of compliance with policies or procedures.
 


PART II
OTHER INFORMATION
 
ITEM 1.  LEGAL PROCEEDINGS
 
Various legal proceedings are pending against us and our subsidiaries.  The resolution of outstanding claims and litigation is subject to inherent uncertainty, and it is reasonably possible that resolution of any of the outstanding claims or litigation matters could have a material adverse effect on us.  See Note 14, “Commitments and Contingencies,” to our “Condensed Consolidated Financial Statements” included under Part I – Item 1 of this report for a discussion of some of these recent changes in our legal proceedings, which Note is incorporated herein by reference.
 
ITEM 1A.  RISK FACTORS
 
In addition to the other information included or incorporated by reference in this quarterly report on Form 10-Q, the following risk factors could also affect our financial condition and results of operations:
 
Demand for our services is cyclical and vulnerable to economic downturns and reductions in government and private industry spending.  If the economy remains weak or client spending declines further, then our revenues, profits and our financial condition may deteriorate.
 
Demand for our services is cyclical and vulnerable to economic downturns and reductions in government and private industry spending, which may result in delaying, curtailing or canceling proposed and existing projects.  In fiscal year 2009 and the first quarter of fiscal year 2010, our clients were affected by the weak economic conditions caused by the declines in the overall economy and constraints in the credit market.  As a result, some clients have delayed, curtailed or cancelled proposed and existing projects and may continue to do so, thus decreasing the overall demand for our services and adversely affecting our results of operations.  We experienced and expect to continue to experience delays or deferrals of existing and proposed projects.  For example, for the three months ended April 2, 2010, we experienced a decline in our revenues compared to the same period in fiscal year 2009.  In light of current macroeconomic conditions, we expect revenues from our power and industrial and commercial market sectors will continue to decline in 2010.  In addition, our clients may find it more difficult to raise capital in the future due to limitations on the availability of credit and other uncertainties in the federal, municipal and corporate credit markets.  Also, our clients may demand more favorable pricing terms and find it increasingly difficult to timely pay invoices for our services, which would impact our future cash flows and liquidity.  In addition, any rapid changes in the prices of commodities make it difficult for our clients and us to forecast future capital expenditures.  Inflation or significant changes in interest rates could reduce the demand for our services.  Any inability to collect our invoices on a timely basis may lead to an increase in our accounts receivables and potentially an increase in the write-offs of uncollectible invoices.  If the economy remains weak or uncertain, or client spending declines further, then our revenues, book of business, net income and overall financial condition could deteriorate.
 


We may not realize the full amount of revenues reflected in our book of business, particularly in light of the current economic conditions, which could harm our operations and could significantly reduce our expected profits and revenues.
 
We account for all contract awards that may eventually be recognized as revenues or equity in income of unconsolidated joint ventures as our “book of business,” which includes backlog, option years and indefinite delivery contracts (“IDCs”).  Our backlog consists of the monetary value of signed contracts, including task orders that have been issued and funded under IDCs and, where applicable, a notice to proceed has been received from the client that is expected to be recognized as revenues when future services are performed.  As of April 2, 2010, our book of business was estimated at approximately $29.9 billion, which included $17.5 billion of our backlog.  Our option year contracts are multi-year contracts with base periods, plus option years that are exercisable by our clients without the need for us to go through another competitive bidding process and would be cancelled only if a client decides to end the project (a termination for convenience) or through a termination for default.  Our IDCs are signed contracts under which we perform work only when our clients issue specific task orders.  Our book of business estimates may not result in realized profits and revenues in any particular period because clients may delay, modify or terminate projects and contracts and may decide not to exercise contract options or issue task orders.  This uncertainty is particularly acute in light of the current economic conditions as the risk of contracts in backlog being delayed or cancelled is more likely to increase during periods of economic volatility.  In addition, our government contracts or subcontracts are subject to renegotiation or termination at the convenience of the applicable U.S. federal, state or local governments, as well as national governments of other countries.  Accordingly, if we do not realize a substantial amount of our book of business, our operations could be harmed and our expected profits and revenues could be significantly reduced.
 
As a government contractor, we must comply with various procurement laws and regulations and are subject to regular government audits; a violation of any of these laws and regulations could result in sanctions, contract termination, forfeiture of profit, harm to our reputation or loss of our status as an eligible government contractor.  Any interruption or termination of our government contractor status could reduce our profits and revenues significantly.
 
As a government contractor, we enter into many contracts with federal, state and local government clients.  For example, revenues from our federal market sector represented 49% of our total revenues for the three months ended April 2, 2010.  We are affected by and must comply with federal, state, local and foreign laws and regulations relating to the formation, administration and performance of government contracts.  For example, we must comply with the Federal Acquisition Regulation (“FAR”), the Truth in Negotiations Act, Cost Accounting Standards (“CAS”), the American Recovery and Reinvestment Act (“ARRA”), the Services Contract Act and DOD security regulations, as well as many other laws and regulations.  In addition, we must also comply with other government regulations related to employment practices, environmental protection, health and safety, tax, accounting and anti-fraud, as well as many others in order to maintain our government contractor status.  These laws and regulations affect how we transact business with our clients and in some instances, impose additional costs on our business operations.  Even though we take precautions to prevent and deter fraud, misconduct and non-compliance, we face the risk that our employees or outside partners may engage in misconduct, fraud or other improper activities.
 


Government agencies, such as the U.S. Defense Contract Audit Agency (“DCAA”), routinely audit and investigate government contractors.  These government agencies review and audit a government contractor’s performance under its contracts, a government contractor’s direct and indirect cost structure, and a government contractor’s compliance with applicable laws, regulations and standards.  For example, during the course of its audits, the DCAA may question our incurred project costs and, if the DCAA believes we have accounted for these costs in a manner inconsistent with the requirements for the FAR or CAS, the DCAA auditor may recommend to our U.S. government corporate administrative contracting officer to disallow such costs.  We can provide no assurance that the DCAA or other government audits will not result in material disallowances for incurred costs in the future.  In addition, government contracts are subject to a variety of other socioeconomic requirements relating to the formation, administration, performance and accounting for these contracts.  We may also be subject to qui tam litigation brought by private individuals on behalf of the government under the Federal Civil False Claims Act, which could include claims for treble damages.  Government contract violations could result in the imposition of civil and criminal penalties or sanctions, contract termination, forfeiture of profit, and/or suspension of payment, any of which could make us lose our status as an eligible government contractor.  We could also suffer serious harm to our reputation.  Any interruption or termination of our government contractor status could reduce our profits and revenues significantly.
 
Employee, agent or partner misconduct or our overall failure to comply with laws or regulations could harm our reputation, reduce our revenues and profits, and subject us to criminal and civil enforcement actions.
 
Misconduct, fraud, non-compliance with applicable laws and regulations, or other improper activities by one of our employees, agents or partners could have a significant negative impact on our business and reputation.  Such misconduct could include the failure to comply with government procurement regulations, regulations regarding the protection of classified information, regulations prohibiting bribery and other foreign corrupt practices, regulations regarding the pricing of labor and other costs in government contracts, regulations on lobbying or similar activities, regulations pertaining to the internal controls over financial reporting, environmental laws and any other applicable laws or regulations.  For example, the United States Foreign Corrupt Practices Act and similar anti-bribery laws in other jurisdictions generally prohibit companies and their intermediaries from making improper payments to non-U.S. officials for the purpose of obtaining or retaining business.  In addition, we regularly provide services that may be highly sensitive or that relate to critical national security matters; if a security breach were to occur, our ability to procure future government contracts could be severely limited.
 
Our policies mandate compliance with these regulations and laws, and we take precautions to prevent and detect misconduct.  However, since our internal controls are subject to inherent limitations, including human error, it is possible that these controls could be intentionally circumvented or become inadequate because of changed conditions.  As a result, we cannot assure that our controls will protect us from reckless or criminal acts committed by our employees and agents.  Failure to comply with applicable laws or regulations or acts of misconduct could subject us to fines and penalties, loss of security clearances, and suspension or debarment from contracting, any or all of which could harm our reputation, reduce our revenues and profits and subject us to criminal and civil enforcement actions.
 


Legal proceedings, investigations and disputes could result in substantial monetary penalties and damages, especially if such penalties and damages exceed or are excluded from existing insurance coverage.
 
We engage in engineering, construction and technical services that can result in substantial injury or damages that may expose us to legal proceedings, investigations and disputes.  For example, in the ordinary course of our business, we may be involved in legal disputes regarding personal injury and wrongful death claims, employee or labor disputes, professional liability claims, and general commercial disputes involving project cost overruns and liquidated damages as well as other claims.  See Note 14, “Commitments and Contingencies,” to our “Condensed Consolidated Financial Statements and Supplementary Data” included under Part I – Item 1 for a discussion of some of our legal proceedings.  In addition, in the ordinary course of our business, we frequently make professional judgments and recommendations about environmental and engineering conditions of project sites for our clients.  We may be deemed to be responsible for these judgments and recommendations if they are later determined to be inaccurate.  Any unfavorable legal ruling against us could result in substantial monetary damages or even criminal violations.  We maintain insurance coverage as part of our overall legal and risk management strategy to minimize our potential liabilities; however, insurance coverage contains exclusions and other limitations that may not cover our potential liabilities.  Generally, our insurance program covers workers' compensation and employer's liability; general liability; automobile liability; professional errors and omissions liability; property; marine property and liability; and contractor’s pollution liability (in addition to other policies for specific projects).  Our insurance program includes deductibles or self-insured retentions for each covered claim.  In addition, our insurance policies contain exclusions and sublimits that insurance providers may use to deny or restrict coverage.  Excess liability and professional liability insurance policies provide for coverages on a “claims-made” basis, covering only claims actually made and reported during the policy period currently in effect.  If we sustain liabilities that exceed or that are excluded from our insurance coverage or for which we are not insured, it could have a material adverse impact on our results of operations and financial condition, including our profits and revenues.
 
Unavailability or cancellation of third-party insurance coverage would increase our overall risk exposure as well as disrupt the management of our business operations.
 
We maintain insurance coverage from third-party insurers as part of our overall risk management strategy and because some of our contracts require us to maintain specific insurance coverage limits.  If any of our third-party insurers fail, suddenly cancel our coverage or otherwise are unable to provide us with adequate insurance coverage then our overall risk exposure and our operational expenses would increase and the management of our business operations would be disrupted.  In addition, there can be no assurance that any of our existing insurance coverage will be renewable upon the expiration of the coverage period or that future coverage will be affordable at the required limits.
 


We may be subject to substantial liabilities under environmental laws and regulations.
 
A portion of our environmental business involves the planning, design, program management, construction and construction management, and operation and maintenance of pollution control and nuclear facilities, hazardous waste or Superfund sites and military bases.  In addition, we have contracts with U.S. federal government entities to destroy hazardous materials, including chemical agents and weapons stockpiles, as well as to decontaminate and decommission nuclear facilities.  These activities may require us to manage, handle, remove, treat, transport and dispose of toxic or hazardous substances.  We must comply with a number of governmental laws that strictly regulate the handling, removal, treatment, transportation and disposal of toxic and hazardous substances.  Under Comprehensive Environmental Response Compensation and Liability Act of 1980, as amended, (“CERCLA”) and comparable state laws, we may be required to investigate and remediate regulated hazardous materials.  CERCLA and comparable state laws typically impose strict, joint and several liabilities without regard to whether a company knew of or caused the release of hazardous substances.  The liability for the entire cost of clean up could be imposed upon any responsible party.  Other principal federal environmental, health and safety laws affecting us include, but are not limited to, the Resource Conservation and Recovery Act, the National Environmental Policy Act, the Clean Air Act, the Clean Air Mercury Rule, the Occupational Safety and Health Act, the Toxic Substances Control Act and the Superfund Amendments and Reauthorization Act.  Our business operations may also be subject to similar state and international laws relating to environmental protection.  Our past waste management practices and contract mining activities as well as our current and prior ownership of various properties may also expose us to such liabilities.  Liabilities related to environmental contamination or human exposure to hazardous substances, or a failure to comply with applicable regulations could result in substantial costs to us, including clean-up costs, fines and civil or criminal sanctions, third-party claims for property damage or personal injury or cessation of remediation activities.  Our continuing work in the areas governed by these laws and regulations exposes us to the risk of substantial liability.
 
Our inability to win or renew government contracts during regulated procurement processes could harm our operations and reduce our profits and revenues.
 
Revenues from our federal market sector represented approximately 49% of our total revenues for the three months ended April 2, 2010.  Government contracts are awarded through a regulated procurement process.  The federal government has increasingly relied upon multi-year contracts with pre-established terms and conditions, such as IDCs, that generally require those contractors that have previously been awarded the IDC to engage in an additional competitive bidding process before a task order is issued.  The increased competition, in turn, may require us to make sustained efforts to reduce costs in order to realize revenues and profits under government contracts.  If we are not successful in reducing the amount of costs we incur, our profitability on government contracts will be negatively impacted.  In addition, the U.S. government has announced its intention to scale back outsourcing of services in favor of “insourcing” jobs to its employees, which could reduce our revenues.  Moreover, even if we are qualified to work on a government contract, we may not be awarded the contract because of existing government policies designed to protect small businesses and under-represented minority contractors.  Our inability to win or renew government contracts during regulated procurement processes could harm our operations and reduce our profits and revenues.
 


Each year, client funding for some of our government contracts may rely on government appropriations or public-supported financing.  If adequate public funding is delayed or is not available, then our profits and revenues could decline.
 
Each year, client funding for some of our government contracts may directly or indirectly rely on government appropriations or public-supported financing such as the ARRA, which provides funding for various clients’ state transportation projects.  Legislatures may appropriate funds for a given project on a year-by-year basis, even though the project may take more than one year to perform.  In addition, public-supported financing such as state and local municipal bonds, may be only partially raised to support existing infrastructure projects.  As a result, a project we are currently working on may only be partially funded and thus additional public funding may be required in order to complete our contract.  Public funds and the timing of payment of these funds may be influenced by, among other things, the state of the economy, competing political priorities, curtailments in the use of government contracting firms, rise in raw material costs, delays associated with a lack of a sufficient number of government staff to oversee contracts, budget constraints, the timing and amount of tax receipts and the overall level of government expenditures.  If adequate public funding is not available or is delayed, then our profits and revenues could decline.
 
Our government contracts may give government agencies the right to modify, delay, curtail, renegotiate or terminate existing contracts at their convenience at any time prior to their completion, which may result in a decline in our profits and revenues.
 
Government projects in which we participate as a contractor or subcontractor may extend for several years.  Generally, government contracts include the right for government agencies to modify, delay, curtail, renegotiate or terminate contracts and subcontracts at their convenience any time prior to their completion.  Any decision by a government client to modify, delay, curtail, renegotiate or terminate our contracts at their convenience may result in a decline in our profits and revenues.
 
If we are unable to accurately estimate and control our contract costs, then we may incur losses on our contracts, which could decrease our operating margins and reduce our profits.
 
It is important for us to accurately estimate and control our contract costs so that we can maintain positive operating margins and profitability.  We generally enter into four principal types of contracts with our clients: cost-plus, fixed-price, target-price and time-and-materials.
 
Under cost-plus contracts, which may be subject to contract ceiling amounts, we are reimbursed for allowable costs and fees, which may be fixed or performance-based.  If our costs exceed the contract ceiling or are not allowable under the provisions of the contract or any applicable regulations, we may not be reimbursed for all of the costs we incur.  Under fixed-price contracts, we receive a fixed price regardless of what our actual costs will be.  Consequently, we realize a profit on fixed-price contracts only if we can control our costs and prevent cost over-runs on our contracts.  Under target-price contracts, project costs are reimbursable and our fee is established against a target budget that is subject to changes in project circumstances and scope.  As a result of the WGI acquisition, the number and size of our target-price and fixed-price contracts have increased, which may increase the volatility of our profitability.  Under time-and-materials contracts, we are paid for labor at negotiated hourly billing rates and for other expenses.
 
If we are unable to accurately estimate and manage our costs, we may incur losses on our contracts, which could decrease our operating margins and significantly reduce or eliminate our profits.  Many of our contracts require us to satisfy specified design, engineering, procurement or construction milestones in order to receive payment for the work completed or equipment or supplies procured prior to achieving the applicable milestone.  As a result, under these types of arrangements, we may incur significant costs or perform significant amounts of work prior to receipt of payment.  If the customer determines not to proceed with the completion of the project or if the customer defaults on its payment obligations, we may encounter difficulties in collecting payment of amounts due to us for the costs previously incurred or for the amounts previously expended to purchase equipment or supplies.
 


Our actual business and financial results could differ from the estimates and assumptions that we use to prepare our financial statements, which may reduce our profits.
 
To prepare financial statements in conformity with GAAP, management is required to make estimates and assumptions as of the date of the financial statements, which affect the reported values of assets and liabilities, revenues and expenses, and disclosures of contingent assets and liabilities.  For example, we may recognize revenues over the life of a contract based on the proportion of costs incurred to date compared to the total costs estimated to be incurred for the entire project.  Areas requiring significant estimates by our management include:
 
·  
the application of the percentage-of-completion method of revenue recognition on contracts, change orders and contract claims;
 
·  
provisions for uncollectible receivables and customer claims and recoveries of costs from subcontractors, vendors and others;
 
·  
provisions for income taxes and related valuation allowances;
 
·  
impairment of goodwill and recoverability of other intangible assets;
 
·  
valuation of assets acquired and liabilities assumed in connection with business combinations;
 
·  
valuation of defined benefit pension plans and other employee benefit plans;
 
·  
valuation of stock-based compensation expense; and
 
·  
accruals for estimated liabilities, including litigation and insurance reserves.
 
Our actual business and financial results could differ from those estimates, which may reduce our profits.
 
Our profitability could suffer if we are not able to maintain adequate utilization of our workforce.
 
The cost of providing our services, including the extent to which we utilize our workforce, affects our profitability.  The rate at which we utilize our workforce is affected by a number of factors, including:
 
·  
our ability to transition employees from completed projects to new assignments and to hire and assimilate new employees;
 
·  
our ability to forecast demand for our services and thereby maintain an appropriate headcount in each of our geographies and workforces;
 
·  
our ability to manage attrition;
 
·  
our need to devote time and resources to training, business development, professional development and other non-chargeable activities; and
 
·  
our ability to match the skill sets of our employees to the needs of the marketplace.
 
If we overutilize our workforce, our employees may become disengaged, which will impact employee attrition.  If we underutilize our workforce, our profit margin and profitability could suffer.
 


Our use of the percentage-of-completion method of revenue recognition could result in a reduction or reversal of previously recorded revenues and profits.
 
A substantial portion of our revenues and profits are measured and recognized using the percentage-of-completion method of revenue recognition.  Our use of this accounting method results in recognition of revenues and profits ratably over the life of a contract, based generally on the proportion of costs incurred to date to total costs expected to be incurred for the entire project.  The effects of revisions to revenues and estimated costs are recorded when the amounts are known or can be reasonably estimated.  Such revisions could occur in any period and their effects could be material.  Although we have historically made reasonably reliable estimates of the progress towards completion of long-term engineering, program management, construction management or construction contracts, the uncertainties inherent in the estimating process make it possible for actual costs to vary materially from estimates, including reductions or reversals of previously recorded revenues and profits.
 
Our failure to successfully bid on new contracts and renew existing contracts could reduce our profits.
 
Our business depends on our ability to successfully bid on new contracts and renew existing contracts with private and public sector clients.  Contract proposals and negotiations are complex and frequently involve a lengthy bidding and selection process, which are affected by a number of factors, such as market conditions, financing arrangements and required governmental approvals.  For example, a client may require us to provide a surety bond or letter of credit to protect the client should we fail to perform under the terms of the contract.  If negative market conditions arise, or if we fail to secure adequate financial arrangements or the required governmental approval, we may not be able to pursue particular projects, which could adversely reduce or eliminate our profitability.
 
If we fail to timely complete a project, miss a required performance standard or otherwise fail to adequately perform on a project, then we may incur a loss on that project, which may reduce or eliminate our overall profitability.
 
We may commit to a client that we will complete a project by a scheduled date.  We may also commit that a project, when completed, will achieve specified performance standards.  If the project is not completed by the scheduled date or fails to meet required performance standards, we may either incur significant additional costs or be held responsible for the costs incurred by the client to rectify damages due to late completion or failure to achieve the required performance standards.  The uncertainty of the timing of a project can present difficulties in planning the amount of personnel needed for the project.  If the project is delayed or canceled, we may bear the cost of an underutilized workforce that was dedicated to fulfilling the project.  In addition, performance of projects can be affected by a number of factors beyond our control, including unavoidable delays from governmental inaction, public opposition, inability to obtain financing, weather conditions, unavailability of vendor materials, changes in the project scope of services requested by our clients, industrial accidents, environmental hazards, labor disruptions and other factors.  In some cases, should we fail to meet required performance standards, we may also be subject to agreed-upon financial damages, which are determined by the contract.  To the extent that these events occur, the total costs of the project could exceed our estimates and we could experience reduced profits or, in some cases, incur a loss on a project, which may reduce or eliminate our overall profitability.
 
We may be required to pay liquidated damages if we fail to meet milestone requirements in some of our contracts.
 
We may be required to pay liquidated damages if we fail to meet milestone requirements in our contracts.  For example, one of our construction projects gives the client the right to assess approximately $25 million if project milestones are not completed by pre-determined dates.  Failure to meet any of the milestone requirements could result in additional costs, and the amount of such additional costs could exceed the projected profits on the project.  These additional costs include liquidated damages paid under contractual penalty provisions, which can be substantial and can accrue on a regular basis.
 


If our partners fail to perform their contractual obligations on a project, we could be exposed to substantial joint and several liability and financial penalties that could reduce our profits and revenues.
 
We often partner with unaffiliated third parties, individually or via a joint venture, to jointly bid on and perform on a particular project.  For example, for the three months ended April 2, 2010, our equity in income of unconsolidated joint ventures amounted to $24.7 million.  The success of our partnerships and joint ventures depends, in large part, on the satisfactory performance of contractual obligations by each member.  In addition, when we operate through a joint venture, we may have limited control over many project decisions, including decisions related to the joint venture’s internal controls, which may not be subject to the same internal control procedures that we employ.  If these unaffiliated third parties do not fulfill their contract obligations, the partnerships or joint ventures may be unable to adequately perform and deliver their contracted services.  Under these circumstances, we may be obligated to pay financial penalties, provide additional services to ensure the adequate performance and delivery of the contracted services and may be jointly and severally liable for the other’s actions or contract performance.  These additional obligations could result in reduced profits and revenues or, in some cases, significant losses for us with respect to the joint venture, which could also affect our reputation in the industries we serve.
 
Our dependence on subcontractors and equipment and material providers could reduce our profits.
 
We rely on third-party subcontractors and equipment and material providers.  For example, we procure heavy equipment and construction materials as needed when performing large construction and contract mining projects.  To the extent that we cannot engage subcontractors or acquire equipment and materials at reasonable costs, our ability to complete a project in a timely fashion or at a profit may be impaired.  If the amount we are required to pay for these goods and services exceed our estimates, we could experience reduced profit or experience losses in the performance of these contracts.  In addition, if a subcontractor or a manufacturer is unable to deliver its services, equipment or materials according to the negotiated terms for any reason, including the deterioration of its financial condition, we may be required to purchase the services, equipment or materials from another source at a higher price.  This may reduce the profit to be realized or result in a loss on a project for which the services, equipment or materials are needed.
 
If we experience delays and/or defaults in client payments, we could suffer liquidity problems or we may be unable to recover all working capital or equity investments.
 
Because of the nature of our contracts, at times we may commit resources in a client’s projects before receiving payments to cover our expenditures.  Sometimes, we incur and record expenditures for a client project before receiving any payment to cover our expenses.  In addition, we may make equity investments in majority or minority controlled large-scale client projects and other long-term capital projects before the project completes operational status or completes its project financing.  If a client project is unable to make its payments, we could incur losses including our working capital or equity investments.
 
The recent tightening of credit could increase this risk, as more clients may be unable to secure sufficient liquidity to pay their obligations.  If a client delays or defaults in making its payments on a project to which we have devoted significant resources, it could have an adverse effect on our financial position and cash flows.
 
Our failure to adequately recover on claims brought by us against project owners for additional contract costs could have a negative impact on our liquidity and profitability.
 
We have brought claims against project owners for additional costs exceeding the contract price or for amounts not included in the original contract price.  These types of claims occur due to matters such as owner-caused delays or changes from the initial project scope, both of which may result in additional cost.  Often, these claims can be the subject of lengthy arbitration or litigation proceedings, and it is difficult to accurately predict when these claims will be fully resolved.  When these types of events occur and unresolved claims are pending, we have used working capital in projects to cover cost overruns pending the resolution of the relevant claims.  A failure to promptly recover on these types of claims could have a negative impact on our liquidity and profitability.
 


Target-price and fixed-price contracts have increased due to our WGI acquisition as well as a shift away from cost-reimbursable contracts by some clients, thus increasing the volatility of our earnings.
 
Our WGI acquisition increased the number and size of our target-price and fixed-price contracts because WGI has historically performed construction-related projects that are more likely to use fixed-price contracts.  In addition, the current administration has encouraged the federal government to increase the use of target-price and fixed-price contracts.  Fixed-price contracts require cost and scheduling estimates that are based on a number of assumptions, including those about future economic conditions, costs and availability of labor, equipment and materials, and other exigencies.  We could experience cost overruns if these estimates are originally inaccurate as a result of errors or ambiguities in the contract specifications, or become inaccurate as a result of a change in circumstances following the submission of the estimate due to, among other things, unanticipated technical problems, difficulties in obtaining permits or approvals, changes in local laws or labor conditions, weather delays, changes in the costs of raw materials, or inability of our vendors or subcontractors to perform.  If cost overruns occur, we could experience reduced profits or, in some cases, a loss for that project.  For example, one of our construction projects has experienced cost increases and schedule delays and we have recorded cumulative project losses of approximately $82.6 million as of April 2, 2010.  If a project is significant, or if there are one or more common issues that impact multiple projects, costs overruns could have a material adverse impact on our business and earnings.
 
Maintaining adequate bonding capacity is necessary for us to successfully bid on and win fixed-price contracts.
 
In line with industry practice, we are often required to provide performance or payment bonds to clients under fixed-price contracts.  These bonds indemnify the customer should we fail to perform our obligations under the contract.  If a bond is required for a particular project and we are unable to obtain an appropriate bond, we cannot pursue that project.  We have bonding capacity but, as is typically the case, the issuance of a bond is at the surety’s sole discretion.  Moreover, due to events that affect the insurance and bonding markets generally, bonding may be more difficult to obtain in the future or may only be available at significantly higher costs.  There can be no assurance that our bonding capacity will continue to be available to us on reasonable terms.  Our inability to obtain adequate bonding and, as a result, to bid on new fixed-price contracts could have a material adverse effect on our business, financial condition, results of operations and cash flows.
 
Construction and project sites are inherently dangerous workplaces.  Failure to maintain safe work sites could result in employee deaths or injuries, reduced profitability, the loss of projects or clients and possible exposure to litigation.
 
Construction and maintenance sites often put our employees and others in close proximity with mechanized equipment, moving vehicles, chemical and manufacturing processes, and highly regulated materials.  On many sites, we are responsible for safety and, accordingly, must implement safety procedures.  If we fail to implement these procedures or if the procedures we implement are ineffective, we may suffer the loss of or injury to our employees, as well as expose ourselves to possible litigation.  As a result, our failure to maintain adequate safety standards could result in reduced profitability or the loss of projects or clients, and could have a material adverse impact on our business, financial condition, and results of operations.
 


If our goodwill or intangible assets become impaired, then our profits will be reduced.
 
A decline in our stock price and market capitalization could result in an impairment of a material amount of our goodwill, which would reduce our earnings.  Goodwill may be impaired if the estimated fair value of one or more of our reporting units’ goodwill is less than the carrying value of the unit’s goodwill.  Because we have grown through acquisitions, goodwill and other intangible assets represent a substantial portion of our total assets.  Goodwill and other net intangible assets were $3.6 billion as of April 2, 2010.  We perform an analysis on our goodwill balances to test for impairment on an annual basis and whenever events occur that indicate impairment could exist.  There are several instances that may cause us to further test our goodwill for impairment between the annual testing periods including:  (i) continued deterioration of market and economic conditions that may adversely impact our ability to meet our projected results; (ii) declines in our stock price caused by continued volatility in the financial markets that may result in increases in our weighted-average cost of capital or other inputs to our goodwill assessment; (iii) the occurrence of events that may reduce the fair value of a reporting unit below its carrying amount, such as the sale of a significant portion of one or more of our reporting units.
 
We also perform an analysis of our intangible assets to test for impairment whenever events occur that indicate impairment could exist.  Examples of such events are i) significant adverse changes in its market value, useful life, physical condition, or in the business climate that could affect its value; ii) a current-period operating or cash flow losses or a projection or forecast that demonstrates continuing losses associated with the use of the intangible asset; and iii) a current expectation that, more likely than not, the intangible asset will be sold or otherwise disposed of before the end of its previously estimated useful life.
 
Changes in environmental, defense, or infrastructure industry laws could directly or indirectly reduce the demand for our services, which could in turn negatively impact our revenues.
 
Some of our services are directly or indirectly impacted by changes in federal, state, local or foreign laws and regulations pertaining to the environmental, defense or infrastructure industries.  For example, passage of the Clean Air Mercury environmental rules increased demand for our emission control services, and any repeal of these rules would have a negative impact on our revenues.  Proposed climate change and greenhouse gas regulations, if adopted, could impact the services we provide to our clients, including services related to fossil fuel and industrial projects.  Relaxation or repeal of laws and regulations, or changes in governmental policies regarding the environmental, defense or infrastructure industries could result in a decline in demand for our services, which could in turn negatively impact our revenues.
 
Limitations of or modifications to indemnification regulations of the U.S. or foreign countries could adversely affect our business.
 
The Price-Anderson Act (“PAA”) comprehensively regulates the manufacture, use and storage of radioactive materials, while promoting the nuclear energy industry by offering broad indemnification to nuclear energy plant operators and DOE contractors.  Because we provide services to the DOE relating to its nuclear weapons facilities and the nuclear energy industry in the ongoing maintenance and modification, as well as the decontamination and decommissioning, of its nuclear energy plants, we may be entitled to some of the indemnification protections under the PAA.  However, the PAA’s indemnification provisions do not apply to all liabilities that we might incur while performing services as a radioactive materials cleanup contractor for the DOE and the nuclear energy industry.  If the PAA’s indemnification protection does not apply to our services or our exposure occurs outside the U.S., our business could be adversely affected by either a refusal to retain us by new facilities operations or our inability to obtain commercially adequate insurance and indemnification.
 

A decline in defense or other federal spending or a change in budgetary priorities could reduce our profits and revenues.
 
Revenues from our federal market sector represented 49% of our total revenues and contracts, of which the Department of Defense (“DOD”) and other defense-related clients represented approximately 33% of our total revenues for the three months ended April 2, 2010.  Past increases in spending authorization for defense-related or other federal programs and in outsourcing of federal government jobs to the private sector are not expected to be sustained on a long-term basis.  For example, the DOD budget declined in the late 1980s and the early 1990s, resulting in DOD program delays and cancellations.  Future levels of expenditures and authorizations for defense-related or other federal programs, including foreign military commitments, may decrease, remain constant or shift to programs in areas where we do not currently provide services.  As a result, a general decline in defense or other federal spending or a change in budgetary priorities could reduce our profits and revenues.
 
Our overall market share and profits will decline if we are unable to compete successfully in our industry.
 
Our industry is highly fragmented and intensely competitive.  For example, according to the publication Engineering News-Record, based on voluntarily reported information, the top ten U.S. design firms accounted only for approximately 40% of the total top 500 U.S. design firm revenues in 2009.  The top 20 U.S. contractors accounted for approximately 41% of the top 400 U.S. contractors revenues in 2008, as reported by the Engineering News Record.  Our competitors are numerous, ranging from small private firms to multi-billion dollar companies.  In addition, the technical and professional aspects of some of our services generally do not require large upfront capital expenditures and provide limited barriers against new competitors.
 
Some of our competitors have achieved greater market penetration in some of the markets in which we compete and have substantially more financial resources and/or financial flexibility than we do.  As a result of the number of competitors in the industry, our clients may select one of our competitors on a project due to competitive pricing or a specific skill set.  If we are unable to maintain our competitiveness, our market share, revenues and profits will decline.  If we are unable to meet these competitive challenges, we could lose market share to our competitors and experience an overall reduction in our profits.
 
Our failure to attract and retain key employees could impair our ability to provide services to our clients and otherwise conduct our business effectively.
 
As a professional and technical services company, we are labor intensive, and, therefore, our ability to attract, retain and expand our senior management and our professional and technical staff is an important factor in determining our future success.  From time to time, it may be difficult to attract and retain qualified individuals with the expertise and in the timeframe demanded by our clients.  For example, some of our government contracts may require us to employ only individuals who have particular government security clearance levels.  We may occasionally enter into contracts before we have hired or retained appropriate staffing for that project.  In addition, we rely heavily upon the expertise and leadership of our senior management.  If we are unable to retain executives and other key personnel, the roles and responsibilities of those employees will need to be filled, which may require that we devote time and resources in identifying, hiring and integrating new employees.  In addition, the failure to attract and retain key individuals could impair our ability to provide services to our clients and conduct our business effectively.

We may be required to contribute cash to meet our underfunded benefit obligations in our employee retirement plans.
 
We have various employee retirement plan obligations that require us to make contributions to satisfy, over time, our underfunded benefit obligations, which are determined by calculating the projected benefit obligations minus the fair value of plan assets.  For example, as of January 1, 2010, our defined benefit pension and post-retirement benefit plans were underfunded by $180.4 million.  In the future, our retirement plan obligations may increase or decrease depending on changes in the levels of interest rates, pension plan asset performance and other factors.  If we are required to contribute a significant amount of the deficit for underfunded benefit plans, our cash flows could be materially and adversely affected.

 
Our inability to successfully integrate acquisitions could impede us from realizing all of the benefits of the acquisition, which could severely weaken our results of operations.
 
Historically, we have used acquisitions as one way to expand our business.  Our inability to successfully integrate future acquisitions could impede us from realizing all of the benefits of those acquisitions and could severely weaken our business operations.  The integration process may disrupt our business and, if implemented ineffectively, may preclude realization of the full benefits expected by us and could seriously harm our results of operations.  In addition, the overall integration of two combining companies may result in unanticipated problems, expenses, liabilities, competitive responses, loss of customer relationships, and diversion of management’s attention, and may cause our stock price to decline.  The difficulties of integrating an acquisition include, among others:
 
·  
unanticipated issues in integrating information, communications and other systems;
 
·  
unanticipated incompatibility of logistics, marketing and administration methods;
 
·  
maintaining employee morale and retaining key employees;
 
·  
integrating the business cultures of both companies;
 
·  
preserving important strategic and customer relationships;
 
·  
consolidating corporate and administrative infrastructures and eliminating duplicative operations;
 
·  
the diversion of management’s attention from ongoing business concerns; and
 
·  
coordinating geographically separate organizations.
 
In addition, even if the operations of an acquisition are integrated successfully, we may not realize the full benefits of the acquisition, including the synergies, cost savings, or sales or growth opportunities that we expect.  These benefits may not be achieved within the anticipated time frame, or at all.
 
Our outstanding indebtedness could adversely affect our liquidity, cash flows and financial condition.
 
As of April 2, 2010, our outstanding balance under the 2007 Credit Facility was $775.0 million.  Our next scheduled payment is due in December 2011.  This level of debt might:
 
·  
increase our vulnerability to, and limit flexibility in planning for, adverse economic and industry conditions;
 
·  
adversely affect our ability to obtain surety bonds;
 
·  
limit our ability to obtain additional financing to fund future working capital, capital expenditures, additional acquisitions and other general corporate initiatives; and
 
·  
limit our ability to apply proceeds from an asset sale to purposes other than the servicing and repayment of debt.

Our access to credit markets may be limited if we require an increased level of debt.
 
If we are required to access the corporate debt markets, we could not be assured that we would be able to finance the required amount in full or at a rate and on terms that are favorable to us.  Currently, the debt markets remain volatile, and success can depend on exogenous variables that impact the overall credit markets, regardless of our inherent qualifications to secure financing.

 
We may not be able to generate or borrow enough cash to service our indebtedness, which could result in bankruptcy or otherwise impair our ability to maintain sufficient liquidity to continue our operations.
 
We rely primarily on our ability to generate cash from operations to service our indebtedness in the future.  If we do not generate sufficient cash flows to meet our debt service and working capital requirements, we may need to seek additional financing.  If we are unable to obtain financing on terms that are acceptable to us, we could be forced to sell our assets or those of our subsidiaries to make up for any shortfall in our payment obligations under unfavorable circumstances.  Our 2007 Credit Facility limits our ability to sell assets and also restricts our use of the proceeds from any such sale.  If we default on our debt obligations, our lenders could require immediate repayment of our entire outstanding debt.  If our lenders require immediate repayment on the entire principal amount, we will not be able to repay them in full, and our inability to meet our debt obligations could result in bankruptcy or otherwise impair our ability to maintain sufficient liquidity to continue our operations.
 
Because we are a holding company, we may not be able to service our debt if our subsidiaries do not make sufficient distributions to us.
 
We have no direct operations and no significant assets other than investments in the stock of our subsidiaries.  Because we conduct our business operations through our operating subsidiaries, we depend on those entities for payments and dividends to generate the funds necessary to meet our financial obligations.  Legal restrictions, including state and local tax regulations and other contractual obligations could restrict or impair our subsidiaries’ ability to pay dividends or make loans or other distributions to us.  The earnings from, or other available assets of, these operating subsidiaries may not be sufficient to make distributions to enable us to pay interest on our debt obligations when due or to pay the principal of such debt at maturity.
 
Restrictive covenants in our 2007 Credit Facility may restrict our ability to pursue business strategies.
 
Our 2007 Credit Facility and our other outstanding indebtedness include covenants limiting our ability to, among other things:
 
·  
incur additional indebtedness;
 
·  
pay dividends to our stockholders;
 
·  
repurchase or redeem our stock;
 
·  
repay indebtedness that is junior to our 2007 Credit Facility;
 
·  
make investments and other restricted payments;
 
·  
create liens securing debt or other encumbrances on our assets;
 
·  
enter into sale-leaseback transactions;
 
·  
enter into transactions with our stockholders and affiliates; and
 
·  
sell or exchange assets.
 
Our 2007 Credit Facility also requires that we maintain various financial ratios, which we may not be able to achieve.  The covenants may impair our ability to finance future operations or capital needs or to engage in other favorable business activities.
 


Our international operations are subject to a number of risks that could significantly reduce our profits and revenues or subject us to criminal and civil enforcement actions.
 
As a multinational company, we have operations in more than 30 countries and we derived 7% of our revenues and equity in income of unconsolidated joint ventures from international operations for the three months ended April 2, 2010.  International business is subject to a variety of risks, including:
 
·  
lack of developed legal systems to enforce contractual rights;
 
·  
greater risk of uncollectible accounts and longer collection cycles;
 
·  
currency fluctuations;
 
·  
logistical and communication challenges;
 
·  
potentially adverse changes in laws and regulatory practices, including export license requirements, trade barriers, tariffs and tax laws;
 
·  
changes in labor conditions;
 
·  
general economic, political and financial conditions in foreign markets; and
 
·  
exposure to civil or criminal liability under the Foreign Corrupt Practices Act, anti-boycott rules, trade and export control rules and other international regulations, for example:
 
o  
Foreign Corrupt Practices Act:  Practices in the local business community outside the U.S. might not conform to international business standards and could violate anticorruption regulations, including the U.S. Foreign Corrupt Practices Act, which prohibits giving or offering to give anything of value with the intent to influence the awarding of government contracts; and
 
o  
Export Control Regulations:  To the extent that we export products, technical data and services outside the U.S., we are subject to U.S. laws and regulations governing international trade and exports, including but not limited to the International Traffic in Arms Regulations, the Export Administration Regulations and trade sanctions against embargoed countries, which are administered by the Office of Foreign Assets Control within the Department of the Treasury.
 
o  
Corporate Manslaughter and Corporate Homicide Act: In the U.K., companies can be found guilty of corporate manslaughter as a result of serious management failures resulting in a gross breach of a duty of care.
 
International risks and violations of international regulations may significantly reduce our profits and revenues and subject us to criminal or civil enforcement actions, including fines, suspensions or disqualification from future U.S. federal procurement contracting.  Although we have policies and procedures to ensure legal and regulatory compliance, our employees, subcontractors and agents could take actions that violate these requirements.  As a result, our international risk exposure may be more or less than the percentage of revenues attributed to our international operations.
 
Our international operations may require our employees to travel to and work in high security risk countries, which may result in employee death or injury, repatriation costs or other unforeseen costs.
 
As a multinational company, our employees often travel to and work in high security risk countries around the world that are undergoing political, social and economic upheavals resulting in war, civil unrest, criminal activity, acts of terrorism, or public health crises.  For example, we have employees working in high security risk countries located in the Middle East and Southwest Asia.  As a result, we risk loss of or injury to our employees and may be subject to costs related to employee death or injury, repatriation or other unforeseen circumstances.
 


We rely on third-party internal and outsourced software to run our critical accounting, project management and financial information systems.  As a result, any sudden loss, disruption or unexpected costs to maintain these systems could significantly increase our operational expense as well as disrupt the management of our business operations.
 
We rely on third-party internal and outsourced software to run our critical accounting, project management and financial information systems.  For example, we rely on one software vendor’s products to process a majority of our total revenues.  We also depend on our software vendors to provide long-term software maintenance support for our information systems.  Software vendors may decide to discontinue further development, integration or long-term software maintenance support for our information systems, in which case we may need to abandon one or more of our current information systems and migrate some or all of our accounting, project management and financial information to other systems, thus increasing our operational expense as well as disrupting the management of our business operations.
 
Force majeure events, including natural and man-made disasters, as well as terrorists risks, have negatively impacted and could further negatively impact our business, which may affect our financial condition, results of operations or cash flows.
 
Force majeure or extraordinary events beyond the control of the contracting parties, such as natural and man-made disasters, as well as terrorist actions, could negatively impact the economies in which we operate.  For example, in August 2005, Hurricane Katrina caused several of our Gulf Coast offices to close, interrupted a number of active client projects and forced the relocation of our employees in that region from their homes.  In addition, during the September 11, 2001 terrorist attacks, many client records were destroyed when our office at the World Trade Center was destroyed.
 
We typically remain obligated to perform our services after such extraordinary events unless the contract contains a force majeure clause relieving us of our contractual obligations in such an extraordinary event.  If we are not able to react quickly to force majeure, our operations may be affected significantly, which would have a negative impact on our financial condition, results of operations or cash flows.
 
Negotiations with labor unions and possible work actions could divert management attention and disrupt operations.  In addition, new collective bargaining agreements or amendments to agreements could increase our labor costs and operating expenses.
 
As of April 2, 2010, approximately 16% of our employees were covered by collective bargaining agreements.  The outcome of any future negotiations relating to union representation or collective bargaining agreements may not be favorable to us.  We may reach agreements in collective bargaining that increase our operating expenses and lower our net income as a result of higher wages or benefit expenses.  In addition, negotiations with unions could divert management attention and disrupt operations, which may adversely affect our results of operations.  If we are unable to negotiate acceptable collective bargaining agreements, we may have to address the threat of union-initiated work actions, including strikes.  Depending on the nature of the threat or the type and duration of any work action, these actions could disrupt our operations and adversely affect our operating results.
 
We have a limited ability to protect our intellectual property rights, which are important to our success.  Our failure to protect our intellectual property rights could adversely affect our competitive position.
 
Our success depends, in part, upon our ability to protect our proprietary information and other intellectual property.  We rely principally on a combination of trade secrets, confidentiality policies and other contractual arrangements to protect much of our intellectual property.  Trade secrets are generally difficult to protect.  Although our employees are subject to confidentiality obligations, this protection may be inadequate to deter or prevent misappropriation of our confidential information.  In addition, we may be unable to detect unauthorized use of our intellectual property or otherwise take appropriate steps to enforce our rights.  Failure to obtain or maintain our intellectual property rights would adversely affect our competitive business position.  In addition, if we are unable to prevent third parties from infringing or misappropriating our intellectual property, our competitive position could be adversely affected.
 


Delaware law and our charter documents may impede or discourage a merger, takeover or other business combination even if the business combination would have been in the best interests of our stockholders.
 
We are a Delaware corporation and the anti-takeover provisions of Delaware law impose various impediments to the ability of a third party to acquire control of us, even if a change in control would be beneficial to our stockholders.  In addition, our Board of Directors has the power, without stockholder approval, to designate the terms of one or more series of preferred stock and issue shares of preferred stock, which could be used defensively if a takeover is threatened.  Our incorporation under Delaware law, the ability of our Board of Directors to create and issue a new series of preferred stock and provisions in our certificate of incorporation and bylaws, such as those relating to advance notice of certain stockholder proposals and nominations, could impede a merger, takeover or other business combination involving us or discourage a potential acquirer from making a tender offer for our common stock, even if the business combination would have been in the best interests of our current stockholders.
 
Our stock price could become more volatile and stockholders’ investments could lose value.
 
In addition to the macroeconomic factors that have recently affected the prices of many securities generally, all of the factors discussed in this section could affect our stock price.  The timing of announcements in the public markets regarding new services or potential problems with the performance of services by us or our competitors or any other material announcements could affect our stock price.  Speculation in the media and analyst community, changes in recommendations or earnings estimates by financial analysts, changes in investors’ or analysts’ valuation measures for our stock and market trends unrelated to our stock can cause the price of our stock to change.  Continued volatility in the financial markets could also cause further declines in our stock price, which could trigger an impairment of the goodwill of our individual reporting units that could be material to our condensed consolidated financial statements.  A significant drop in the price of our stock could also expose us to the risk of securities class action lawsuits, which could result in substantial costs and divert managements’ attention and resources, which could adversely affect our business.
 


ITEM 2.  UNREGISTERED SALES OF EQUITY SECURITIES AND USE OF PROCEEDS
 
Issuer Purchases of Equity Securities
 
The following table sets forth all purchases made by us or any “affiliated purchaser” as defined in Rule 10b-18(a)(3) of the Securities Exchange Act of 1934, as amended, of our common shares during the three monthly periods that comprise our third quarter of 2009.
 
Period (In thousands, except average price paid per share)
 
(a) Total Number of Shares Purchased (1)
   
(b) Average Price Paid per Share
   
(c) Total Number of Shares Purchased as Part of Publicly Announced Plans or Programs (2)
   
(d) Maximum Number of Shares that May Yet be Purchased Under the Plans or Programs
 
January 2, 2010 – January 29, 2010
        $              
January 30, 2010 – February 26, 2010
    19       45.99              
February 27, 2010 – April 2, 2010
    280       49.48       1,000       3  
Total                                  
    299               1,000       3  

(1)  
Reflects purchases of shares previously issued pursuant to awards issued under our equity incentive plans, which allow our employees to surrender shares of our common stock as payment toward the exercise cost and tax withholding obligations associated with the exercise of stock options or the vesting of restricted or deferred stock.
 
 
(2)  
On March 26, 2007, we announced that our Board of Directors approved a common stock repurchase program that will allow the repurchase of up to one million shares of our common stock plus additional shares issued or deemed issued under our stock incentive plans and Employee Stock Purchase Plan for the period from December 30, 2006 through January 1, 2010 (excluding shares issuable upon the exercise of options granted prior to December 30, 2006).  On February 26, 2010, the Board of Directors approved an extension of the stock repurchase period from January 2, 2010 through December 28, 2012.  Under our 2007 Credit Facility, as amended, we are subject to covenants that will limit our ability to repurchase our common stock.  However, we amended our 2007 Credit Facility on June 19, 2008 so that we are allowed to repurchase up to one million shares of common stock annually if we maintain various designated financial criteria.  During the three months ended April 2, 2010, we repurchased an aggregate of 1.0 million shares of our common stock.
 
 
We are precluded by provisions in our 2007 Credit Facility from paying cash dividends on our outstanding common stock until our Consolidated Leverage Ratio is equal to or less than 1.00:1.00.
 
ITEM 3.  DEFAULTS UPON SENIOR SECURITIES
 
None.
 
ITEM 4.  RESERVED AND REMOVED
 
None.
 
ITEM 5.  OTHER INFORMATION
 
None.
 


ITEM 6.  EXHIBITS
 
(a)      Exhibits
 
         
Incorporated by Reference
   
 
Exhibit Number
 
Exhibit Description
 
Form
 
Exhibit
 
Filing Date
 
Filed Herewith
 
3.01
 
Restated Certificate of Incorporation of URS Corporation, as filed with the Secretary of State of Delaware on September 9, 2008.
 
8-K
 
3.01
 
9/11/2008
   
                 
X
                 
X
 
10.1*
 
Description of Base Salary, 2010 Performance Metrics and Target Bonuses.
 
8-K
 
N/A
 
3/26/2010
   
 
10.2*
 
URS Corporation Restated Incentive Compensation Plan 2010 Plan Year Summary.
 
8-K
 
10.1
 
3/26/2010
   
                 
X
                 
X
                 
X
                 
X
                 
X
                 
X
                 
    X**
 
 
*
Represents a management contract or compensatory plan or arrangement.
 
 
**
Document has been furnished and not filed and not to be incorporated into any of our filings under the Securities Act of 1933 or the Securities Exchange Act of 1934, irrespective of any general incorporation language included in any such filing.
 
 

 


SIGNATURES
 
Pursuant to the requirements of the Securities Exchange Act of 1934, the Registrant has duly caused this report to be signed on its behalf by the undersigned thereunto duly authorized.
 
 
URS CORPORATION
 
       
Dated:  May 12, 2010
By:
/s/ Reed N. Brimhall  
   
Reed N. Brimhall
 
   
Vice President, Controller and Chief Accounting Officer
 
       
 
 

 


 

 
 
Exhibit No.
 
 
Description
 
 
 
 
 
 
 
 
 
 
75